10-K
Table of Contents

 

 

UNITED STATES

SECURITIES AND EXCHANGE COMMISSION

Washington, D.C. 20549

 

 

Form 10-K

ANNUAL REPORT PURSUANT TO SECTION 13 OR 15(d)

OF THE SECURITIES EXCHANGE ACT OF 1934

For the fiscal year ended December 31, 2011

Commission File Number 001-08106

 

 

 

LOGO

MasTec, Inc.

(Exact Name of Registrant as Specified in Its Charter)

 

Florida   65-0829355

(State or Other jurisdiction of

Incorporation or Organization)

 

(I.R.S. Employer

Identification No.)

800 S. Douglas Road, 12th Floor,

Coral Gables, FL

  33134
(Address of Principal Executive Offices)   (Zip Code)

(305) 599-1800

(Registrant’s Telephone Number, Including Area Code)

Securities registered pursuant to Section 12(b) of the Exchange Act:

Title of Each Class

 

Name of Each Exchange on Which Registered

Common Stock, $0.10 Par Value   New York Stock Exchange

Securities registered pursuant to Section 12(g) of the Exchange Act: None

 

 

Indicate by check mark if the registrant is a well-known seasoned issuer; as defined in rule 405 of the Securities Act.    Yes  x    No  ¨

Indicate by check mark if the registrant is not required to file reports pursuant to Section 13 or Section 15(d) of the Act.    Yes  ¨    No  x

Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days.    Yes  x    No  ¨

Indicate by check mark whether the registrant has submitted electronically and posted on its corporate Web site, if any, every Interactive Data File required to be submitted and posted pursuant to Rule 405 of Regulation S-T (§ 232.405 of this chapter) during the preceding 12 months (or for such shorter period that the registrant was required to submit and post such files).    Yes  x    No  ¨

Indicate by check mark if disclosure of delinquent filers pursuant to Item 405 of Regulation S-K (Section 229.405 of this chapter) is not contained herein, and will not be contained, to the best of registrant’s knowledge, in definitive proxy or information statements incorporated by reference in Part III of this Form 10-K or any amendment to this Form 10-K. x

Indicate by check mark if the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, or a smaller reporting company. See the definitions of “large accelerated filer”, “accelerated filer”, and “smaller reporting company” in Rule 12b-2 of the Exchange Act. (Check one):

 

Large accelerated filer   x    Accelerated filer   ¨
Non-accelerated filer   ¨    Smaller reporting company   ¨

Indicate by check mark whether the registrant is shell company (as defined in Rule 12b-2 of the Act.)    Yes  ¨    No  x

The aggregate market value of the registrant’s outstanding common stock held by non-affiliates of the registrant computed by reference to the price at which the common stock was last sold as of the last business day of the registrant’s most recently completed second fiscal quarter was $1,248,777,748 (based on a closing price of $19.72 per share for the registrant’s common stock on the New York Stock Exchange on June 30, 2011).

There were 80,647,396 shares of common stock outstanding as of February 27, 2012.

The registrant’s definitive proxy statement to be filed with the Securities and Exchange Commission pursuant to Regulation 14A for the 2011 annual meeting of shareholders is incorporated by reference in Part III of this Form 10-K to the extent stated herein.

 

 

 


Table of Contents

TABLE OF CONTENTS

 

     Page  

Part I

     4   

Item 1

  

Business

     4   

Item 1A

  

Risk Factors

     13   

Item 1B

  

Unresolved Staff Comments

     27   

Item 2

  

Properties

     27   

Item 3

  

Legal Proceedings

     27   

Item 4

  

Mine Safety Disclosures

     27   

Part II

     27   

Item 5

  

Market for the Registrant’s Common Equity, Related Stockholder Matters and Issuer Purchases of Equity Securities

     27   

Item 6

  

Selected Financial Data

     29   

Item 7

  

Management’s Discussion and Analysis of Financial Condition and Results of Operations

     30   

Item 7A

  

Quantitative and Qualitative Disclosures About Market Risk

     54   

Item 8

  

Financial Statements and Supplementary Data

     55   

Item 9

  

Changes in and Disagreements with Accountants on Accounting and Financial Disclosure

     100   

Item 9A

  

Controls and Procedures

     100   

Item 9B

  

Other Information

     102   

Part III

     102   

Item 10

  

Directors, Executive Officers and Corporate Governance

     102   

Item 11

  

Executive Compensation

     102   

Item 12

  

Security Ownership of Certain Beneficial Owners and Management and Related Stockholder Matters

     103   

Item 13

  

Certain Relationships and Related Transactions, and Director Independence

     103   

Item 14

  

Principal Accounting Fees and Services

     103   

Part IV

     103   

Item 15

  

Exhibits and Financial Statement Schedules

     103   

Signatures

     108   

 

2


Table of Contents

Cautionary Statement Regarding Forward-Looking Statements

We are making this statement pursuant to the safe harbor provisions for forward-looking statements described in the Private Securities Litigation Reform Act of 1995. We make statements in this Annual Report on Form 10-K and in the documents that we incorporate by reference into this Annual Report that are forward-looking. When used in this Annual Report or in any other presentation, statements which are not historical in nature, including the words “anticipate,” “estimate,” “could,” “should,” “may,” “plan,” “seek,” “expect,” “believe,” “intend,” “target,” “will,” “project” and variations of these words and negatives thereof and similar expressions are intended to identify forward-looking statements. They also include statements regarding:

 

   

our future growth and profitability;

 

   

our competitive strengths; and

 

   

our business strategy and the trends we anticipate in the industries and economies in which we operate.

These forward-looking statements are based on our current expectations and are subject to a number of risks, uncertainties and assumptions. These statements are not guarantees of future performance and are subject to risks, uncertainties and other factors, some of which are beyond our control, are difficult to predict, and could cause actual results to differ materially from those expressed or forecasted in the forward-looking statements. Important factors that could cause actual results to differ materially from those in forward-looking statements include:

 

   

market conditions, technical and regulatory changes that affect us or our customers’ industries;

 

   

further or continued economic downturns, reduced capital expenditures, reduced financing availability, customer consolidation and technological and regulatory changes in the industries we serve;

 

   

the timing and extent of fluctuations in geographic, weather, equipment and operational factors affecting the industries in which we operate;

 

   

our ability to estimate the costs associated with our fixed price and other contracts and performance on such projects;

 

   

increases in labor, fuel, maintenance, materials and other costs;

 

   

the highly competitive nature of our industry;

 

   

the impact of any unionized workforce, or related labor organization efforts on our operations, including labor availability and relations;

 

   

liabilities associated with multiemployer union pension plans, including underfunded liabilities, for our operations that employ unionized workers;

 

   

trends in electricity, oil, natural gas and other energy source prices;

 

   

the effect of state and federal regulatory initiatives, including costs of compliance with existing and future environmental requirements;

 

   

the impact of the American Recovery and Reinvestment Act of 2009 (the “ARRA”) and any federal, state or local incentives or regulations affecting renewable energy, electrical transmission, broadband and related projects and expenditures;

 

   

risks associated with operating in international markets, which could restrict our ability to expand globally and harm our business and prospects or any failure to comply with laws applicable to our foreign activities;

 

   

our ability to replace non-recurring projects with new projects;

 

   

the ability of our customers, including our largest customers, to terminate or reduce the amount of work, or in some cases prices paid for services on short or no advance notice under our contracts;

 

   

our dependence on a limited number of customers;

 

   

the potential sale of DirectStar TV LLC (“DirectStar”) and its subsidiaries upon exercise by Red Ventures LLC of its option to purchase DirectStar from us;

 

3


Table of Contents
   

our ability to retain qualified personnel and key management, including from acquired businesses, enforce any noncompetition agreements, integrate acquired businesses within expected timeframes and achieve the revenue, cost savings and earnings levels from such acquisitions at or above the levels projected;

 

   

our ability to attract and retain qualified managers and skilled employees;

 

   

the outcome of our plans for future operations, growth and services, including business development efforts, backlog and acquisitions;

 

   

our ability to obtain performance and surety bonds;

 

   

restrictions imposed by our credit facility, senior notes, convertible notes and any future loans or securities;

 

   

the adequacy of our insurance, legal and other reserves and allowances for doubtful accounts;

 

   

any material changes in estimates for legal costs or case settlements or adverse determinations on any claim, lawsuit or proceeding;

 

   

liquidity issues related to our investment in securities available for sale;

 

   

any exposure related to our divested state Department of Transportation projects and assets;

 

   

any dilution or stock price volatility that shareholders may experience in connection with shares we may issue as consideration for earn-out obligations or as purchase price consideration in connection with past or future acquisitions, or as a result of conversions of convertible notes or other stock issuances;

 

   

our ability to settle conversions of our convertible notes in cash due to contractual restrictions, including those contained in our credit facility, and the availability of cash; and

 

   

the other factors referenced in this Annual Report, including, without limitation, under Item 1. “Business,” Item 1A “Risk Factors,” Item 7. “Management’s Discussion and Analysis of Financial Condition and Results of Operations” and other factors detailed from time to time in the reports and other filings we make with the Securities and Exchange Commission.

We believe these forward-looking statements are reasonable; however, you should not place undue reliance on any forward-looking statements, which are based on current expectations. Furthermore, forward-looking statements speak only as of the date they are made. If any of these risks or uncertainties materialize, or if any of our underlying assumptions are incorrect, our actual results may differ significantly from the results that we express in, or imply by, any of our forward-looking statements. These and other risks are detailed in this Annual Report on Form 10-K, in the documents that we incorporate by reference into this Annual Report on Form 10-K and in other documents that we file with the Securities and Exchange Commission. We do not undertake any obligation to publicly update or revise these forward-looking statements after the date of this Annual Report on Form 10-K to reflect future events or circumstances, except as required by applicable law. We qualify any and all of our forward-looking statements by these cautionary factors.

PART I

ITEM 1. BUSINESS

Overview

We are a leading infrastructure construction company operating mainly throughout North America across a range of industries. Our activities include, but are not limited to, the engineering, building, installation, maintenance and upgrade of energy, utility and communications infrastructure, including: electrical utility transmission and distribution, power generation, natural gas and petroleum pipeline infrastructure, wireless, wireline and satellite communications, wind farms, solar farms and other renewable energy, industrial infrastructure and water and sewer systems. Our customers are primarily in the utility, communications and government industries.

Including our predecessor companies, we have been in business for more than 80 years. We offer our services primarily under the MasTec service mark and, as of December 31, 2011, we had approximately 10,000 employees and more than 400 locations. We have consistently been ranked among the top specialty contractors by Engineering News-Record over the past five years.

 

4


Table of Contents

We serve a diversified customer base, and our customers include some of the leading communications and utility companies in the United States. For the year ended December 31, 2011, our top ten customers were DIRECTV®, AT&T, El Paso Corporation, Energy Transfer Company, Talisman Energy, Mid-American Energy, Dominion Virginia Power, DCP Midstream, Spectra Energy and EQT Corporation. We have longstanding relationships and have developed strong alliances with many of our customers, and we strive to maintain these customer relationships and our status as a preferred vendor. More than half of our services are provided under multi-year master service agreements and other service agreements.

We have actively pursued a diversification and expansion strategy in recent years. This strategy has deepened our presence and expanded our service offerings in key markets, including wireless, natural gas and petroleum pipeline, electrical transmission, renewable energy and heavy industrial, among others. In addition to integration and growth opportunities associated with our diversification and expansion strategy, we also seek opportunities to expand our geographic presence as well as new opportunities in traditional business areas, such as telecommunications and install-to-the-home services.

For additional information, refer to Part II, Item 7, “Management’s Discussion and Analysis of Financial Condition and Results of Operations.” and Item 8, “Financial Statements and Supplementary Data.”

Industry Trends

Our industry is composed of national, regional and local companies that provide services to customers in the utilities and communications industries as well as to government entities.

We believe the following industry trends impact demand for our services:

Increased Production and Demand for Pipelines

Natural gas is one of the cleanest burning hydrocarbon fuels and is in demand because of its relative cost advantage over other fossil fuel sources. The level of natural gas pipeline construction activity in the United States is expected to increase due to the desire to promote domestic sources of energy. The North American Electric Reliability Corporation (“NERC”), is the organization of United States electric grid operators. According to NERC’s 2011 Long-Term Reliability Assessment, natural gas has become the predominant option for new build power generation as gas-fired plants are typically easy to construct, require little lead-time, emit less carbon dioxide, and are generally less expensive to construct when compared to coal and oil generation facilities. In its report, NERC notes that certain states have placed or are expected to place a moratorium on building new coal plants, citing environmental and emissions concerns as justification. These trends are anticipated to continue over the next several years, further increasing the expected number of new build natural gas plants.

According to NERC’s 2011 report, development of unconventional gas production in North America has the potential to increase availability of gas supply in the future. Higher estimates of available North American natural gas come from access to unconventional sources such as shale formations, which previously had been difficult and expensive to reach. Gas in shale formations represents an estimated two-thirds of North America’s potentially recoverable gas reserves. Coupled with higher availability of unconventional natural gas supplies, developers could substantially increase gas-fired plant additions, changing the North American fuel mix while increasing dependency on a single, largely domestic fuel type. Natural gas consumption is at all-time highest levels and is expected to increase over the next ten years. The recent technological advances in horizontal drilling and hydraulic fracturing, which have led to the current natural gas drilling boom, are expected to positively affect exploration and production of oil and natural gas liquids in the near future. Robust gas shale drilling in recent years has created an abundance of gas supply, which has reduced the price of dry gas, or gas without imbedded liquids, that can be extracted for higher value. Industry experts predict that more domestic drilling will shift to areas where crude and high-value gas liquid by-products can be produced with gas. The same drilling and completion technologies which have expanded production in the gas shale regions are expected to offer the same benefits in the oil shale regions or liquids-rich areas of the gas shale basins. Expanded opportunities for liquids pipelines are expected in the Bakken, Eagle Ford, Permian, Western Marcellus, Utica and other liquids-rich shale basins.

We believe that as new unconventional shale gas reserves are developed, the demand for additional gas transport projects will grow. We also believe that U.S. energy policy goals will continue to promote domestic sources of energy in order to reduce U.S. dependence on foreign energy sources, both for economic and national security reasons. According to the Interstate Natural Gas Association of America’s (“INGAA”) North American National Gas Midstream Infrastructure Through 2035 report dated June 2011, the U.S. and Canada will need over 43 billion cubic feet per day (“Bcfd”) of incremental mainline capacity from 2010 to 2035 to accommodate the anticipated changes in natural gas supply and demand. The INGAA report estimates that annual expenditures for pipeline infrastructure, including gathering and processing facilities, will average over $8.0 billion per year over the next 25 years.

Our acquisitions have expanded our presence and deepened our capabilities in natural gas and petroleum pipeline infrastructure, including the construction and maintenance of large diameter pipeline, mid-stream pipeline, compressor and pump stations and treatment plants. We anticipate that increased demand for natural gas and petroleum pipeline infrastructure will provide robust pipeline and heavy industrial construction opportunities, and that our diverse capabilities and expertise in these sectors will enable us to be a leading player in this growing market.

 

5


Table of Contents

Increased Demand for Wireless and Wired Services

Demand for faster and more robust wireless and wired services has increased significantly with the proliferation of the internet, broadband, data transmission, high definition television, video and music download services and other advanced video services. Data usage over wireless networks is rapidly increasing as more consumers surf the web, check email and watch video on mobile devices. Smartphones, laptops and other mobile devices have become increasingly important to consumers and an October 2010 study by the Federal Communications Commission (“FCC”) estimated that mobile data demand will exceed available wireless capacity in the near-term, growing to between 25 and 50 times the current level of demand within 5 years. To serve this developing market and the ever-increasing need for more bandwidth and faster voice, video and data services for fixed and mobile devices, service providers continue to upgrade the capacity and performance of their wired and wireless networks and are deploying competing networks using new technologies. Investment is facilitated by declining equipment costs and expanded capabilities of wireline and wireless network equipment. At the same time, major regional and rural telecommunication companies are upgrading their networks from copper line to fiber optic line in order to enhance their ability to provide customers with bundled services that include video, voice and data. Similar dynamics of providers seeking to improve their offerings are prevalent in the cable and satellite markets as well. The ARRA has allocated $7.2 billion for the development of broadband facilities throughout the United States and the expansion of broadband access into areas that are currently not served by high-speed data networks.

Inadequacy of Existing Electric Power Transmission and Distribution Networks

The United States’ electric transmission and distribution infrastructure requires significant ongoing maintenance, upgrades and extensions to manage power line congestion and avoid delivery failures. Demand for electricity is expected to continue to grow as the economy recovers and as the population grows. According to the 2012 Annual Energy Outlook published by the DOE’s Energy Information Administration, the U.S. population will increase by about 25% from 2010 to 2035, with energy consumption increasing by 10%. NERC reports in its 2011 Long-Term Reliability Assessment that peak demand for electricity in the United States is forecast to increase by approximately 14% over the next ten years. To accommodate the increase in demand, NERC estimates that 34,000 circuit miles will need to be added to the electrical transmission system in the United States over the next ten years. Significant capital investment in the U.S. transmission and distribution system will be required to meet the needs of the growing population as well as the projected increase in use of renewable resources. In March 2011, the Edison Electric Institute (“EEI”) projected over $60 billion of investments in new transmission systems will be made over the twenty year period from 2010 to 2021.

Significant investment in new transmission lines will also be required to connect new renewable energy generation projects to the electrical grid. Renewable energy power sources are typically located in remote areas. Wind power generation is only feasible where adequate average wind speed and consistency are present. The principal onshore wind resource in the United States is located in the central plains area of the country, roughly from the Texas panhandle to the Canadian border. This wind corridor is a relatively remote area where population density and industrial energy demand are relatively low. As a result, relatively few traditionally fueled generation facilities exist in these areas; therefore, extensive collection and transmission projects are necessary to connect these renewable energy generation projects to the electrical grid. In a March 2011 report, the EEI estimated that almost $40 billion will be invested from 2010 through 2021 to address the integration of renewable resources through the addition or upgrade of nearly 11,400 circuit miles of transmission. Also driving the expected growth in renewable energy related transmission projects are the current state level renewable portfolio standards. According to an October 2010 report by The Brattle Group, if the current renewable portfolio standards were increased to a 20% federal renewable portfolio standard, the investment requirement over the next 10 to 15 years would increase to between $80 billion and $130 billion.

In addition to projects aimed at increasing electrical power transmission capacity and integration of new renewable energy resources, efforts to modernize the existing transmission system are also expected. The category of projects using digital technology to improve reliability, security and efficiency of the electric system are known as “Smart Grid” projects. The ARRA allocates $11 billion in funds for modernization and expansion of the nation’s electrical grid in order to develop a Smart Grid.

We believe that spending levels will continue to increase as utilities work to address infrastructure maintenance, reliability and capacity requirements, as well as future reliability standards required by the Energy Policy Act of 2005 and state mandated renewable portfolio standards.

Renewable Energy Projects

The desire to decrease the country’s dependence on foreign oil imports and the focus on a clean environment have created demand for more domestic, environmentally sensitive electrical power production such as wind and solar collection farms. According to a January 2011 report published by the U.S. Environmental Protection Agency (“EPA”), as of May 2011, 38 states plus the District of Columbia have enacted a renewable portfolio standard or goal. These standards require or target that specified percentages of energy sales or installed capacity come from renewable sources such as wind, solar, geothermal or biofuel. NERC’s 2010 Long-Term Reliability Assessment projects approximately 180,000 megawatts (“MW”) of new wind and solar capacity over the next ten years, and indicates that wind and solar

 

6


Table of Contents

resources account for 95 percent of anticipated renewable resource additions by 2019. Our recent expansion and diversification efforts have deepened our expertise in wind, solar and industrial plant construction, and we expect to be a leading player in renewable energy infrastructure projects. We also believe that our business will benefit from opportunities resulting from the ARRA, which calls for expansion of domestic renewable energy sources through tax incentives and loan guarantees.

Wind Opportunities

Currently, approximately 2% of the United States’ electrical needs are met by wind power generation. The new generation of wind turbines can produce electrical power at more competitive rates than those of older generation wind turbines. A July 2008 report by the DOE presents a roadmap for increasing wind power generation to 20% of demand by 2030 which would require hundreds of billions of dollars in new wind farm investment and transmission lines.

According to the American Wind Energy Association, as of December 31, 2011, the United States had approximately 47,000 MW of installed wind farm generating capacity, with approximately 6,800 MW added in 2011 and approximately 5,200 MW added in 2010. There were approximately 5,600 MW under construction as of December 31, 2011, and NERC projects that approximately 166,000 MW of new wind resources will be added to the power system by 2019. In connection with this anticipated growth, Emerging Energy Research forecasts that more than $66 billion will be invested in additional wind energy capacity in the United States through 2013. We believe that demand for new domestic sources of clean power generation and the related substations and transmission lines necessary to connect them to the electrical grid will provide significant growth prospects for the foreseeable future; however, if Congress does not extend or renew the production tax credit, the levels of installed wind farm generating capacity are expected to decrease significantly in 2013. See Item 1A – Risk Factors – “The impact of the American Recovery and Reinvestment Act of 2009 is uncertain.”

Solar Opportunities

The U.S. photovoltaic (“PV”) market has grown at an average annual rate of 69% over the past ten years, rising from 3.9 MW in 2000 to 435 MW in 2009. In 2010, PV installations doubled versus 2009, rising to over 880 MW. According to the Solar Energy Industries Association (“SEIA”), as of the end of the third quarter of 2011, the U.S. had already achieved a record year, surpassing 1 gigawatt (“GW”) of PV installations. Total additions in 2011 are expected to be 1.7 GW. The increase in demand has been driven, in part, by federal and state-level incentives as well as improved project economics. With continued declines in PV manufacturing costs and strong renewable energy incentives, SEIA believes that the U.S. could become the world’s largest solar market in 2014. In addition to PV market growth, approximately 60 MW of concentrating solar power (“CSP”) are projected to have been added in 2011. In its 2010 report, NERC projects over 12,000 MW of solar power additions over the next ten years. We believe that we are well positioned with our solar customers for future projects.

Heavy Industrial Opportunities

Industrial plant construction opportunities across a wide variety of industries are present. The low price of natural gas is expected to spur the construction of new gas-fired electrical generating plants, conversions of coal-fired power plants to cleaner natural gas and the construction of other plants which use natural gas as a fuel source or chemical feedstock. Industrial facilities and plants that support the natural gas, petroleum and related industries present opportunities as additional domestic energy reserves are produced, transported and processed.

Tax Incentives

The ARRA was enacted in February 2009 and contained federal tax incentives applicable to the renewable energy industry. Certain key renewable energy provisions contained in the ARRA were extended in December 2010. These provisions should have a positive impact on our customers’ spending in a number of important areas and offer additional incentives that should benefit our business. One of the federal tax incentives contained in the ARRA is the extension of the production tax credit for wind projects placed into service before December 31, 2012. The production tax credit provides the owner of a U.S. wind facility with a ten-year credit against its federal income tax obligations based on the amount of electricity produced at such facility by the owner and sold to unrelated persons during that period. The wind industry, however, will be negatively impacted if the production tax credit is not extended or renewed in 2012. The ARRA also allowed wind and solar projects to elect to claim an investment tax credit equal to 30% of the cost of certain qualifying assets in lieu of claiming the production tax credit. The ARRA also includes a U.S. Treasury grant program which allows taxpayers that own production tax credit-eligible and investment tax credit-eligible facilities to receive grants from the U.S. Treasury equal to the amount of the investment tax credit that would otherwise be available to the facility. The ARRA tax incentives have a finite duration, and third-party efforts to extend or renew such incentives may not be successful.

The accelerated depreciation provision for renewable energy generation assets provides for a five year depreciable life for these assets, rather than the 15 to 20 year depreciable lives of many non-renewable energy assets. First year bonus depreciation is also available for eligible renewable energy systems. Under this provision, 100% of the eligible basis may be deducted in the first year for eligible systems acquired and placed in service between September 8, 2010 and December 31, 2011 and 50% of the eligible basis may be deducted in the first year for eligible systems acquired and placed in service during 2012. Historically, incentives such as these have increased construction

 

7


Table of Contents

activity in this sector and are expected to do so in the future. The ARRA also contains several provisions aimed at improving the electrical transmission system in the U.S., in part to facilitate the transfer of renewable energy from rural areas to high demand areas, including at least $6 billion in funds for renewable energy and transmission loan guarantees, which are expected to facilitate more than $60 billion in loans for these projects.

Competitive Strengths

Our competitive strengths include:

Diverse Customer Relationships. We serve a diversified customer and industry base. Our customers include some of the largest communications, utility and energy companies in the United States, including DIRECTV®, AT&T, El Paso Corporation, Energy Transfer Company, Talisman Energy, Mid-American Energy, Dominion Virginia Power, DCP Midstream, Spectra Energy and EQT Corporation. We have longstanding relationships with many customers and often provide services to many of our customers under multi-year master service agreements and other service agreements. We believe that as a result of our expansion and diversification efforts, it is unlikely that a single customer will account for greater than 30% of our revenue in the near future.

National Footprint. Including our predecessor companies, we have been in business for more than 80 years and are one of the largest companies in the infrastructure construction services industry. Through our network of more than 400 locations and approximately 10,000 employees as of December 31, 2011, we offer consistent, comprehensive infrastructure services to our customers throughout North America. We believe our experience, technical expertise, geographic reach and size are important to our customers.

Ability to Respond Quickly and Effectively. The skills required to serve our end markets are similar, which allows us to utilize qualified personnel across multiple end markets and projects. We are able to respond quickly and effectively to industry changes, demand and major weather events by allocating our employees, fleet and other assets as and where they are needed, enabling us to provide cost effective and timely services for our customers.

Reputation for Reliable Customer Service and Technical Expertise. We believe that over the years, we have established a reputation for quality customer service and technical expertise. We believe that our reputation gives us an advantage in competing for new work, both from existing as well as from potential customers. In addition, our recent acquisitions have broadened our capabilities and expertise in the areas of wireless, pipeline, electrical transmission, renewable energy and heavy industrial infrastructure.

Experienced Management Team. Our management team plays a significant role in establishing and maintaining long-term relationships with our customers, supporting the growth of our business, integrating acquired businesses and managing the financial aspects of our operations. Our chief executive officer, president, chief operating officer and business unit presidents average 20 plus years of industry experience and have a deep understanding of our customers and their requirements. Generally, key managers and founders of our recently acquired companies continue to work for us under long-term employment agreements or services agreements.

Strategy

The key elements of our business strategy are as follows:

Focus on Growth Opportunities. We believe that our end markets offer compelling growth opportunities. We expect increased spending by key customers in the industries we serve. We expect development of natural gas and petroleum pipeline infrastructure, expansion of wireless infrastructure, electrical transmission capacity and distribution grid expansion and upgrades, development of renewable energy infrastructure, including wind and solar farms, and heavy industrial projects to be areas of high investment and opportunity in the coming years. We intend to use our North American presence, technical expertise, customer relationships and full range of services to capitalize on these trends and grow our business.

Operational Excellence. We seek to improve our operating margins and cash flows by focusing on profitable services and projects that have high margin potential, as well as by identifying opportunities for leverage within our business, such as deploying resources across multiple projects, while maintaining strong working capital management practices. We strive to improve our operating effectiveness and utilization rates by allocating resources across multiple customers and projects, where possible. We intend to continue actions and programs that have been instituted to improve operating efficiencies and working capital management, such as increasing accountability throughout our organization, managing customer contract bidding procedures more effectively and increasing individual project profitability, hiring additional experienced operating and financial professionals, and expanding the use of our financial and other management information systems.

Maintain Conservative Capital Structure. We have increased our financial resources in recent years. In August 2011, we amended our credit facility, which expanded our borrowing capacity from $260 million to $600 million. We also completed a debt exchange in the first quarter of 2011, resulting in the exchange of 94% of two of our outstanding series of senior convertible notes that were originally issued in 2009. The terms of the exchanged notes are substantially identical to those of the original notes, except that the exchanged notes have an optional physical (share), cash or combination settlement feature. See Note 9 – Debt in the notes to the consolidated financial statements for details. Further, during the past three years, two of the major ratings agencies reaffirmed our credit ratings.

 

8


Table of Contents

Focus on Acquisition Integration. We have diversified our business and expanded our service offerings through several acquisitions in the last few years. Our strategy includes timely and efficient integration of these acquisitions to best fit into our internal control environment and to maximize the potential of the acquisitions.

Leverage Core Expertise Through Acquisitions and Strategic Alliances. We may pursue selected acquisitions, investments and strategic alliances that allow us to expand our operations into targeted geographic areas or continue to expand our service offerings in related fields.

Services

Our core services are the engineering, building, installing, maintaining and upgrading of infrastructure for communications, utility and government customers. We provide similar services to each of these customers, including:

Build. We build infrastructure projects for customers across a range of industries. We specialize in building natural gas, crude oil and refined product transport pipelines; underground and overhead distribution systems, including trenches, conduits, cable and power lines, which provide wireless and wireline communications; electrical power generation, transmission and distribution systems; renewable energy infrastructure, including wind and solar farms; and compressor and pump stations and treatment plants and heavy industrial plants.

Install. We install buried and aerial fiber optic cables, coaxial cables, copper lines, electrical and other energy distribution systems, transmission systems and satellite dishes in a variety of environments for our customers. In connection with our installation work, we deploy and manage network connections that involve our customers’ hardware, software and network equipment.

Maintain and Upgrade. We offer 24-hours-a-day, 7-days-a-week and 365-days-a-year maintenance and upgrade support to our customers. Our comprehensive service offerings include the regular maintenance of our customers’ distribution facilities, networks and infrastructure, including natural gas and petroleum pipeline, wireless and electrical distribution and transmission infrastructure. We also provide emergency services for accidents or storm damage. Our upgrade work ranges from routine replacements and upgrades to major overhauls.

Customers

We have longstanding relationships with many customers, and more than half of our revenue is derived from projects performed under service agreements and master service agreements, which are generally multi-year agreements. Certain of our master service agreements are exclusive up to a specified dollar amount per work order for each defined geographic area but do not obligate our customers to undertake any infrastructure projects or other work with us. Work performed under master service and other service agreements is typically generated by work orders, each of which is performed for a fixed fee. Services provided under master service and other service agreements range from engineering and installation work to maintenance and upgrade services. These master service agreements and other service agreements are frequently awarded on a competitive bid basis, although customers may negotiate contract extensions beyond their original terms without re-bidding. Our master service and other service agreements have various terms, depending upon the nature of the services provided and are typically subject to termination on short or no advance notice.

The remainder of our work is generated pursuant to contracts for specific projects that may require the construction and installation of specified units within an infrastructure system or an entire infrastructure system. Customers are billed with varying frequency: weekly, monthly or upon attaining specific milestones. Such contracts generally include retainage provisions under which 2% to 15% of the contract price is withheld until the work has been completed and accepted by the customer.

We believe that our industry experience, technical expertise and reputation for customer service, as well as the relationships developed between our customers and our senior management and project management teams are important to our being retained by large utility and communications companies as well as government entities. Revenue concentration information, as a percent of total consolidated revenue, is as follows:

 

     For the Years Ended December 31,  
     2011     2010     2009  

Revenue from top ten customers

     71     72     72

Revenue from specific customers:

      

DIRECTV®

     23     24     30

AT&T

     23     20     16

 

9


Table of Contents

Refer to Note 3 – Acquisitions and Other Investments in the notes to the consolidated financial statements for additional information regarding the purchase option agreement with Red Ventures LLC, which is exercisable beginning March 1, 2012 and, if exercised, could materially reduce future revenues from DIRECTV®.

Backlog

Estimated backlog represents the amount of revenue we expect to realize over the next 18 months from future work on uncompleted contracts, including new contractual agreements on which work has not begun. Our backlog estimates include amounts under master service and other service agreements in addition to construction projects. We determine the amount of backlog for work under master service and other service agreements based on historical trends, anticipated seasonal impacts and estimates of customer demand based on communications with our customers. The following presents 18-month backlog for our business as of the periods indicated (in millions):

 

     As of December 31  
     2011      2010  

Estimated 18-month backlog

   $ 3,339.1       $ 2,354.5   
  

 

 

    

 

 

 

We expect to realize approximately 75% of our year end 2011 backlog in 2012. While our backlog estimates include amounts under master service and other service agreements, our customers are not contractually committed to purchase a minimum amount of services under these agreements, most of which can be cancelled on short or no advance notice. There can be no assurance as to our customers’ requirements or that our estimates are accurate. In addition, timing of revenues for construction and installation projects included in our backlog can be subject to change as a result of customer delays, regulatory requirements and other project related factors. These changes could cause estimated revenues to be realized in periods later than originally expected, or not at all. As a result, our backlog as of any particular date is an uncertain indicator of future revenues and earnings.

Sales and Marketing

Our customers increasingly require resources from multiple disciplines. Therefore, we market our services individually or in combination with other companies to provide what we believe is the most efficient and effective solution to meet our customers’ demands. Through our unified MasTec® brand and an integrated organizational structure designed to permit rapid deployment of labor, equipment and materials, we are able to quickly and efficiently allocate resources to meet customer needs.

We have developed a marketing plan emphasizing the MasTec® registered service mark and tradenames of certain acquired companies, as well as an integrated service offering to position ourselves as a provider of a full range of service solutions, providing services ranging from basic installation to sophisticated engineering, design and integration. We believe our long-standing relationships with our customers and reputation for reliability and efficiency facilitate our recurring business. Our marketing efforts are principally carried out by the management of our business units and project groups in coordination with our corporate marketing organization. Our management team has many years of industry experience, both at the service provider level and in some cases with the customers we serve. Our business unit and project group managers market directly to existing and potential customers for new contracts and also market our company to be placed on lists of vendors invited to submit proposals for service agreements and individual projects. Our executive management supplements these efforts at the national level.

Safety and Insurance/Risk Management

We strive to instill safe work habits in our employees. We require our employees to participate in training programs relevant to their employment and to complete all training programs required by law. We evaluate employees in part based upon their safety records and the safety records of the employees they supervise. We have established a company-wide safety program to share best practices and to monitor and improve compliance with safety procedures and regulations.

Our business involves the use of heavy equipment and exposure to various workplace conditions that can be dangerous. While we are committed to operating safely and prudently, we are subject to claims by employees, customers and third parties for property damage and personal injuries that occur in connection with our work. We presently maintain insurance policies subject to per claim deductibles of $1 million for our workers’ compensation policy, $2 million for our general liability policy and $2 million for our automobile liability policy. We have excess umbrella coverage of up to $100 million per claim and in the aggregate. We also maintain an insurance policy with respect to employee group health claims subject to annual per employee maximum losses of $0.4 million. See Item 1A. Risk Factors – “We are self-insured against many potential liabilities.” We are required to post letters of credit and provide cash collateral to certain of our insurance carriers and to obtain surety bonds in certain states in which we are self-insured. Total outstanding letters of credit related to our insurance programs amounted to $51.4 million, and cash collateral deposited with insurance carriers amounted to $2.0 million as of December 31, 2011. Outstanding surety bonds related to self-insurance programs amounted to $7.1 million as of December 31, 2011. See Item 7. “Management’s Discussion and Analysis of Financial Condition and Results of Operations – Critical Accounting Policies and Estimates – Self-Insurance.”

 

10


Table of Contents

Suppliers, Materials and Working Capital

Under many of our contracts, our customers provide the necessary materials and supplies for projects and we are responsible for the installation of, but not the cost or warranty of those materials. Under certain of our other projects, we purchase the necessary materials and supplies on behalf of our customers from third-party providers. We are not dependent on any one supplier for materials or supplies and have not experienced any significant difficulty in obtaining an adequate supply of materials and supplies.

We utilize independent contractors to assist on projects and to help us manage work flow. Our independent contractors are typically sole proprietorships or small business entities that provide their own vehicles, tools and insurance coverage. We are not dependent on any single independent contractor. We need working capital to support seasonal variations in our business, primarily due to the impact of weather conditions on external construction and maintenance work and the spending patterns of our customers, both of which influence the timing of associated spending to support related customer demand. Our business is typically slower in the first quarter of each calendar year. Accordingly, we generally experience seasonal working capital needs from approximately April through December to support growth in unbilled revenue and accounts receivable, and to a lesser extent, inventory. Timing of project close-outs can also contribute to fluctuations in unbilled revenue, which can impact our working capital needs. Our billing terms are generally net 30 days, although some contracts allow our customers to retain a portion (from 2% to 15%) of the contract amount until the job is completed. For certain customers, we maintain inventory to meet the material requirements of the contracts. Occasionally, certain of our customers pay us in advance for a portion of the materials we purchase for their projects, or allow us to pre-bill them for materials purchases up to a specified amount. Vendor terms are generally 30 days. Our agreements with subcontractors often contain a “pay-when-paid” provision, whereby our payments to subcontractors are made only after we are paid by our customers.

Competition

Our industry is highly competitive and highly fragmented. We often compete with a number of companies in the markets in which we operate, ranging from small local independent companies to large national firms. The national or large regional firms that compete with us include Quanta Services, Inc., MYR Group, Inc., Dycom Industries, Inc., Pike Electric, Inc., Bechtel Corporation, M.A. Mortenson Company and D.H. Blattner & Sons, Inc.

Relatively few significant barriers to entry exist in the markets in which we operate and as a result, any organization that has adequate financial resources and access to technical expertise may become a competitor. Some of our customers employ personnel to perform infrastructure services of the type we provide. We compete based upon our industry experience, technical expertise, financial and operational resources, North American presence, industry reputation and customer service. While we believe our customers consider a number of factors when selecting a service provider, most of their work is awarded through a bid process. Consequently, price is often a principal factor in determining which service provider is selected. See Item 1A. Risk Factors – “Our industry is highly competitive, which may reduce our market share and harm our financial performance.”

Regulation and Environmental Matters

We are subject to state and federal laws that apply to businesses generally, including laws and regulations related to labor relations, worker safety and environmental protection. While many of our customers operate in regulated industries (for example, utilities regulated by the public service commission or communications companies regulated by the Federal Communications Commission), we are not generally subject to such regulation and oversight.

As a contractor, our operations are subject to various laws, including:

 

   

regulations related to vehicle registrations, including those of state and the United States Department of Transportation;

 

   

regulations related to worker safety and health, including those established by the Occupational Safety and Health Administration;

 

   

contractor licensing requirements;

 

   

permitting and inspection requirements; and

 

   

building and electrical codes.

We are also subject to numerous environmental laws governing our operations, including the handling, transportation and disposal of non-hazardous and hazardous substances and wastes, as well as emissions and discharges into the environment, including discharges into air, surface water and groundwater and soil. We also are subject to laws and regulations that impose liability and cleanup responsibility for releases of hazardous substances into the environment. Under certain of these laws and regulations, liabilities can be imposed for cleanup of properties, regardless of whether we directly caused the contamination or violated any law at the time of discharge or disposal. The presence of contamination from such substances or wastes could interfere with ongoing operations or adversely affect our business. In addition, we could be held liable for significant penalties and damages under certain environmental laws and regulations. For example,

 

   

Some of the work we perform is in underground environments. If the field location maps supplied to us are not accurate, or if objects are present in the soil that are not indicated on the field location maps, our underground work could strike objects in the soil containing pollutants and result in a rupture and discharge of pollutants. In such a case, we may be liable for fines and damages.

 

11


Table of Contents
   

We own and lease several facilities at which we store our equipment. Some of these facilities contain fuel storage tanks which may be above or below ground. If these tanks were to leak, we could be responsible for the cost of remediation as well as potential fines.

 

   

We sometimes perform directional drilling operations in certain environmentally sensitive terrains and water bodies. Due to the inconsistent nature of the terrain and water bodies, it is possible that such directional drilling may cause a surface fracture releasing subsurface materials. These releases may contain contaminants in excess of amounts permitted by law, potentially exposing us to remediation costs and fines.

We believe we have all licenses and permits needed to conduct operations and that we are in compliance with all material applicable regulatory requirements. However, if we fail to comply with any material applicable regulatory requirements, we could incur significant liabilities.

We offer services and are branded under the MasTec® service mark and other service marks.

Financial Information About Geographic Areas

In April 2011, we expanded our foreign operations through the acquisition of Fabcor Target Co Ltd., a Canadian natural gas and petroleum pipeline infrastructure construction company. We also have foreign operations in parts of Latin America and the Caribbean. For the three years in the period ended December 31, 2011, revenues of $91.4 million, $3.4 million and $6.2 million, respectively, were derived from foreign operations. In addition, we held property and equipment in foreign countries of $12.7 million and $1.4 million as of December 31, 2011 and 2010, respectively.

Our business, financial condition and results of operations in foreign countries may be adversely affected by monetary and fiscal policies, currency fluctuations, energy shortages, regulatory requirements and other political, social and economic developments or instability. Refer to Item 1A – “Risk Factors” for additional information.

Employees

As of December 31, 2011, we had approximately 10,000 employees, approximately 310 of whom were represented by a union or were subject to collective bargaining agreements. These collective bargaining agreements require us to pay specified wages and provide certain benefits to these employees, including contributions to multi-employer pension plans and employee benefit trusts. The collective bargaining agreements expire at various times and have typically been renegotiated and renewed on terms that are similar to the ones contained in the expiring agreements. See Item 1A, Risk Factors – “Certain of our businesses have employees who are represented by a union or are subject to collective bargaining agreements; the unionized workforce and any related obligations could adversely affect our operations.”

We hire employees from a number of sources, including our industry, trade schools and colleges. Our primary sources for employees include promotion from within, team member referrals, print and internet advertising and direct recruiting. We attract and retain employees by offering technical training opportunities, bonus opportunities, stock ownership, competitive salaries and a comprehensive benefits package.

We believe that our focus on training and career development helps us to attract and retain employees. Our employees participate in ongoing educational programs, many of which are internally developed, to enhance their technical and management skills through classroom and field training. We provide opportunities for promotion and mobility within our organization, which we also believe helps us to retain our employees. We believe our relations with our employees are good.

Available Information

A copy of this Annual Report on Form 10-K, as well as our Quarterly Reports on Form 10-Q, Current Reports on Form 8-K and any amendments to those reports filed or furnished pursuant to Section 13 or 15(d) of the Securities Exchange Act of 1934 are available free of charge on the internet at our website, www.mastec.com, as soon as reasonably practicable after we electronically file these reports with, or furnish these reports to, the Securities and Exchange Commission, which we refer to as the SEC. Copies of our Board of Directors Governance Principles and Code of Business Conduct and Ethics, which applies to all directors and employees and includes a code of ethics

 

12


Table of Contents

for our CEO, CFO, president and other senior executives, and which expressly applies to our senior financial officers (including our principal executive officer, principal financial officer, president and our controller), and the charters for each of our Audit, Compensation and Nominating and Corporate Governance Committees are also available on our website in the Investor section under the tab “Corporate Governance,” or may be obtained by contacting our Vice President of Investor Relations by phone at (305) 406-1815, or by email at investor.relations@mastec.com. We intend to provide any amendments or waivers to our Code of Business Conduct and Ethics for any of our directors and senior officers on our website within four business days of any such amendment or waiver. The reference to our website address does not constitute incorporation by reference of the information contained on the website and such information is not part of this report. Our reports filed with the SEC may be read or copied at the SEC’s Public Reference Room at 100 F Street, NE, Washington, D.C. 20549. Information on the operation of the SEC’s Public Reference Room may be obtained by calling the SEC at 1-800-SEC-0330. Alternatively, you may access these reports at the SEC’s website at www.sec.gov.

 

ITEM 1A. RISK FACTORS

You should carefully consider the risks described below, together with all of the other information in this Annual Report on Form 10-K. The risks described below are not the only risks facing us. Additional risks and uncertainties not currently known to us or that we currently deem to be immaterial may also materially and adversely affect our business operations. If any of these risks actually occur, our business, financial condition and results of operations could suffer and the trading price of our common stock could decline.

Risks Related to Our Industry and Our Customers’ Industries

Economic downturns could reduce capital expenditures in the industries we serve, which may result in a decrease in demand for our services.

The demand for our services has been, and will likely continue to be, cyclical in nature and vulnerable to general downturns in the U.S. economy. Given the continuing economic downturn, our customers may not have the ability to fund capital expenditures for infrastructure, or may have difficulty obtaining financing for planned projects. This has, and may continue to result in cancellations of projects or deferral of projects to a later date, such as those experienced in connection with certain of our renewable energy and wireless projects during 2011. Such cancellations or deferrals could result in decreased demand for our services and could materially adversely affect the results of our operations, cash flows and liquidity.

In addition, our customers are affected by economic downturns that decrease the need for their services or the profitability of their services. Slow-downs in real estate, fluctuations in commodity prices and decreased demand by end-customers for services could affect our customers and their capital expenditure plans. Because we have previously been negatively impacted by economic downturns, we continually monitor our customers’ industries and their relative health compared to the economy as a whole. Reductions in new housing starts, for example, have negatively affected our customers who utilize our services to construct their “last mile” of communications infrastructure, as well as other industries we serve, including electric utility transmission and grid connection, as well as water and sewer and natural gas pipeline construction. Additionally, our customers who provide satellite and broadband communications to consumers across the country could be adversely impacted by an economic downturn if new subscriptions and upgrades for new and existing consumers are not ordered at the rate that our customers anticipate. During an economic downturn, like the current economic downturn, our customers also may not have the ability or desire to continue to fund capital expenditures for infrastructure or may determine to outsource less work. A decrease in any of these projects, new subscriptions and upgrades or any other services we provide could materially adversely affect our results of operations, cash flows and liquidity.

Our industry is highly competitive, which may reduce our market share and harm our financial performance.

Our industry is highly fragmented, and we compete with other companies in most of the markets in which we operate, ranging from small independent firms servicing local markets to larger firms servicing regional and national markets. We also face competition from existing or prospective customers that employ in-house personnel to perform some of the same types of services we provide. There are relatively few barriers to entry into certain of the markets in which we operate and, as a result, any organization that has adequate financial resources and access to technical expertise and skilled personnel may become one of our competitors.

Most of our customers’ work is awarded through a bid process. Consequently, price is often the principal factor in determining which service provider is selected, especially on smaller, less complex projects. Smaller competitors are sometimes able to win bids for these projects based on price alone due to their lower costs and financial return requirements. If we are unsuccessful in bidding on these projects, or if our ability to win such projects requires that we accept lesser margins, then our results of operations, cash flows and liquidity could be materially and adversely affected.

 

13


Table of Contents

Many of the industries we serve are subject to consolidation and rapid technological and regulatory change, and our inability or failure to adjust to our customers’ changing needs could reduce demand for our services.

We derive, and anticipate that we will continue to derive, a substantial portion of our revenue from customers in the communications and utilities industries. The communications and utilities industries are subject to rapid changes in technology and governmental regulation. Changes in technology may reduce the demand for the services we provide. For example, new or developing technologies could displace the wireline systems used for the transmission of voice, video and data, and improvements in existing technology may allow communications providers to significantly improve their networks without physically upgrading them. Technological advances may also result in lower costs for sources of energy, which may render existing wind energy, solar energy and natural gas projects and technologies uncompetitive or obsolete. Additionally, the communications and utilities industries have been characterized by a high level of consolidation that may result in the loss of one or more of our customers. Our failure to rapidly adopt and master new technologies as they are developed in any of the industries we serve or the consolidation of one or more of our significant customers could have a material adverse effect on our results of operations, cash flows and liquidity.

Risks Related to Our Business

We derive a significant portion of our revenue from a few customers, and the loss of one of these customers or a reduction in their demand for our services could impair our financial performance.

For the year ended December 31, 2011, we derived approximately 23%, 23% and 8% of our revenue from DIRECTV®, AT&T and El Paso Corporation, respectively. For the year ended December 31, 2010, we derived approximately 24%, 20% and 9% of our revenue from DIRECTV®, AT&T and El Paso Corporation, respectively, and for the year ended December 31, 2009, we derived approximately 30%, 16%, 7% and 5% of our revenue from DIRECTV®, AT&T, Enbridge and Verizon, respectively. In addition, our ten largest customers accounted for approximately 71%, 72% and 72% of our revenue in each of the three years ended December 31, 2011, 2010 and 2009, respectively. Because our business is concentrated among relatively few major customers, and certain of our services are provided on a non-recurring, project by project basis, we could experience a reduction in our results of operations, cash flows and liquidity if the amount of business we obtain from these customers is reduced, or if we complete the required work on our projects and cannot replace them with similar projects. Just over 40% of our revenues were derived from non-recurring project specific work for the year ended December 31, 2011, which may further increase this risk if we are not able to replace completed project work with new work. In addition, many of the contracts with our largest customers may be canceled on short or no advance notice. Any of these factors could negatively impact our results of operations, cash flows and liquidity.

Additionally, pursuant to our February 2011 amended and restated purchase option agreement with Red Ventures LLC (“Red Ventures”), Red Ventures has an option to purchase DirectStar and its subsidiaries (which, in support of the DIRECTV® installation business, provides marketing and sales services on behalf of DIRECTV®) from MasTec at any time from March 1, 2012 to November 30, 2012, for an amount equal to the sum of: (i) the shareholders’ equity of DirectStar as of May 31, 2010, (ii) five percent (5%) of adjusted net income (generally, the net income (loss) before provision for income taxes) of DirectStar from January 1, 2010 until the last day of the month immediately prior to the date of the sale and (iii) $25,600,000. Should Red Ventures exercise its purchase option, our revenues and profits from DIRECTV® would be reduced. DirectStar accounted for $148.5 million and $143.3 million of our revenues in 2011 and 2010, respectively. Based upon current discussions with Red Ventures, we currently anticipate that the sale of DirectStar will occur in the second quarter of 2012; however, we cannot provide any assurance that Red Ventures will exercise its option or that any sale will occur.

Most of our contracts do not obligate our customers to undertake any infrastructure projects or other work with us.

More than half of our revenue is derived from multi-year master service agreements and other service agreements. Under our multi-year master service agreements and other service agreements, we contract to provide customers with individual project services, through work orders, within defined geographic areas on a fixed fee basis. Under these agreements, our customers have no obligation to undertake any infrastructure projects or other work with us. A significant decline in the projects customers assign us under these service agreements could result in a decline in our results of operations, cash flows and liquidity.

Most of our contracts may be canceled on short or no advance notice, so our revenue is not guaranteed. Additionally, certain of our contracts with customers are subject to their ability to secure financing or other conditions and therefore may not result in revenues or profits.

Most of our contracts are cancelable on short or no advance notice, ranging from immediate cancellation to cancellation upon 180 days notice, even if we are not in default under the contract. Many of our contracts, including our service agreements, are periodically open to public bid. We may not be the successful bidder on our existing contracts that are re-bid. We also provide a significant portion of our services on a non-recurring, project-by-project basis. We could experience a reduction in our revenue, profitability and liquidity if:

 

   

our customers cancel a significant number of contracts;

 

   

we fail to win a significant number of our existing contracts upon re-bid; or

 

   

we complete the required work under a significant number of our non-recurring projects and cannot replace them with similar projects.

 

14


Table of Contents

Additionally, from time to time, we may announce the award of certain contracts. These contracts may contain financing or other conditions and therefore may not result in revenues or profits if our customers are unable to obtain the associated financing or any other conditions associated with such projects are otherwise not met.

Amounts included in our backlog may not result in actual revenue or translate into profits. Our backlog is subject to cancellation and unexpected adjustments and therefore is an uncertain indicator of future operating results.

A significant portion of our 18-month backlog at December 31, 2011 was composed of master service agreements and other service agreements, none of which require our customers to purchase a minimum amount of services and are cancelable on short or no advance notice. The balance of our backlog is our estimate of work to be completed on long-term installation/construction fixed price agreements. These backlog amounts are based on our estimates and therefore may not result in actual receipt of revenue in the originally anticipated period, or at all. In addition, contracts included in our backlog may not be profitable. We may experience variances in the realization of our backlog because of project delays or cancellations resulting from weather conditions, other project deferrals or delays, scope adjustments, external market factors and economic factors beyond our control. If our backlog fails to materialize, our results of operations, cash flows and liquidity would be materially and adversely affected. Accordingly, our backlog as of any particular date is an uncertain indicator of future earnings.

Our business is seasonal and is affected by adverse weather conditions and the spending patterns of our customers, exposing us to variable quarterly results.

Some of our customers reduce their expenditures and work order requests towards the end of the year. Adverse weather conditions, particularly during the winter season, also affect our ability to perform outdoor services in certain regions of North America. As a result, we experience reduced revenue in the first quarter of each calendar year. Natural catastrophes such as hurricanes or other severe weather could also have, and have had, a negative impact on the economy overall and on our ability to perform outdoor services in affected regions or utilize equipment and crews stationed in those regions, which could result in a decline in results of operations, cash flows and liquidity. For example, the northeastern United States was negatively affected by flooding in the second half of 2011. Heavy rains began in the summer, followed by additional rainfall from Hurricane Irene in August and Tropical Storm Lee in September, causing flooding conditions, which hurt productivity and profitability on certain of our pipeline projects in the Marcellus shale basin.

We may not accurately estimate the costs associated with our services provided under fixed price contracts, which could impair our financial performance.

A substantial portion of our revenue is derived from master service agreements and other service agreements that are fixed price contracts. Under these contracts, we set the price of our services on a per unit or aggregate basis and assume the risk that the costs associated with our performance may be greater than we anticipated. In addition to master or other service agreements, we enter into contracts that require installation or construction of specified units within an infrastructure system. Under those agreements, we have also contractually agreed to a price per unit. Profitability will be reduced if the actual costs to complete each unit exceed original estimates. We are also required to immediately recognize the full amount of any expected losses on these projects if estimated costs to complete the remaining units for the projects exceed the revenue to be earned on such units. Our profitability is therefore dependent upon our ability to accurately estimate the costs associated with our services. These costs may be affected by a variety of factors, such as lower than anticipated productivity, conditions at the work sites differing materially from what was anticipated at the time we bid on the contract and higher costs of materials and labor. These variations, along with other risks inherent in performing fixed price contracts, may cause actual project revenue and gross profit to differ from original estimates, and as a result, certain agreements or projects could have lower margins than anticipated, or losses, if actual costs exceed our estimates, which could reduce our profitability, cash flows and liquidity.

We recognize revenue for our installation/construction fixed price contracts using the percentage-of-completion method, therefore, variations of actual results from our assumptions may reduce our profitability.

We recognize revenue on long-term installation/construction fixed price contracts using the percentage-of-completion method. Under the percentage-of-completion method, we record revenue as work on the contract progresses. The cumulative amount of revenue recorded on a contract at a specified point in time is that percentage of total estimated revenue that incurred costs to date bear to estimated total contract costs. The percentage-of-completion method therefore relies on estimates of total expected contract costs. Contract revenue and total cost estimates are reviewed and revised periodically as the work progresses. Adjustments are reflected in contract revenue in the fiscal period in which such estimates are revised. Estimates are based on management’s reasonable assumptions and experience, but are only estimates. Variation of actual results from estimates on a large project or on a number of smaller projects could be material. We immediately recognize the full amount of an estimated loss on a contract when our estimates indicate such a loss. Such adjustments and accrued losses could result in reduced profitability, which could negatively impact our liquidity.

 

15


Table of Contents

Our failure to properly manage projects, or project delays, may result in additional costs or claims, which could have a material adverse effect on our operating results, cash flows and liquidity.

Certain of our engagements involve large-scale, complex projects. The quality of our performance on such a project depends in large part upon our ability to manage our client relationship and the project itself and to timely deploy appropriate resources, including third-party contractors and our own personnel. Our results of operations, cash flows and liquidity could be adversely affected if we miscalculate the resources or time needed to complete a project with capped or fixed fees, or the resources or time needed to meet contractual milestones. Additionally, delays on a particular project, including permitting delays, may cause us to incur costs for standby pay, and may lead to personnel shortages on other projects scheduled to commence at a later date. In addition, some of our agreements require that we share in cost overages or pay liquidated damages if we do not meet project deadlines; therefore, any failure to properly estimate or manage cost, or delay in the completion of projects could subject us to penalties which could further adversely affect our results of operations, cash flows and liquidity. Further, any defects or errors, or failures to meet our customers’ expectations could result in large damage claims against us, and because of the substantial cost of, and potentially long lead-times necessary to acquire certain of the materials and equipment used in our complex projects, in particular on our pipeline and renewable energy projects, damage claims may substantially exceed the amount we can charge for our associated services.

We may be unable to obtain sufficient bonding capacity to support certain service offerings, and the need for performance and surety bonds may reduce our availability under our credit facility.

Some of our contracts require performance and payment bonds. If our business continues to grow, our bonding requirements may increase. If we are not able to renew or obtain a sufficient level of bonding capacity in the future, we may be precluded from being able to bid for certain contracts or successfully contract with certain customers. In addition, even if we are able to successfully renew or obtain performance or payment bonds, we may be required to post letters of credit in connection with the bonds, which would reduce availability under our credit facility.

Increases in our insurance premiums or collateral requirements could significantly reduce our profitability, liquidity and availability under our credit facility.

Because of factors such as increases in claims, projected significant increases in medical costs and wages, lost compensation and reductions in coverage, insurance carriers may be unwilling to continue to provide us with our current levels of coverage without a significant increase in insurance premiums or collateral requirements to cover our deductible obligations. An increase in premiums or collateral requirements could significantly reduce our profitability and liquidity as well as reduce availability under our revolving credit facility.

We are self-insured against many potential liabilities.

Although we maintain insurance policies with respect to automobile liability, general liability, workers’ compensation and employee group health claims, those policies are subject to high deductibles, and we are self-insured up to the amount of the deductible. Since most claims against us do not exceed the deductibles under our insurance policies, we are effectively self-insured for substantially all claims. We actuarially determine any liabilities for unpaid claims and associated expenses, including incurred but not reported losses, and reflect the present value of those liabilities in our balance sheet as other current and non-current liabilities. The determination of such claims and expenses and the appropriateness of the related liability is reviewed and updated quarterly. However, insurance liabilities are difficult to assess and estimate due to the many relevant factors, the effects of which are often unknown, including the severity of an injury, the determination of our liability in proportion to other parties, the number of incidents not reported and the effectiveness of our safety program. If our insurance claims increase or if costs exceed our estimates of insurance liabilities, we could experience a decline in profitability and liquidity.

Warranty claims resulting from our services could have a material adverse effect on our business.

We generally warrant the work we perform for a one to two-year period following substantial completion of a project, subject to further extensions of the warranty period following repairs or replacements. We have not historically accrued reserves for potential warranty claims as they have been immaterial. The costs associated with such warranties, including any warranty related legal proceedings, could have a material adverse effect on our results of operations, cash flows and liquidity.

Demand for pipeline construction services depends on oil and natural gas industry activity and expenditure levels that are directly affected by trends in oil, natural gas and other fuel prices and the cost of energy infrastructure projects.

Demand for our pipeline construction services is particularly sensitive to the level of exploration, development, and production activity of, and the corresponding capital spending by, oil and natural gas companies. Prices for oil and natural gas are subject to large fluctuations in response to relatively minor changes in the supply of and demand for oil and natural gas, market uncertainty, and a variety of other factors that are beyond our control. Low prices for oil and natural gas generally depress levels of exploration, development and production activity, resulting in a corresponding decline in the demand for pipeline construction services. Factors affecting the prices of oil and natural gas include:

 

   

the levels of supply and demand for oil and natural gas, especially demand for natural gas in the United States;

 

16


Table of Contents
   

governmental regulations, including policies regarding the exploration, production and development of oil and natural gas reserves as well as environmental laws and initiatives to control global warming;

 

   

global weather conditions and natural disasters;

 

   

worldwide political, military, and economic conditions; the level of oil production by non-OPEC countries and available excess production capacity within OPEC;

 

   

oil refining capacity and shifts in end-customer preferences toward fuel efficiency and the use of natural gas;

 

   

the cost of producing and delivering oil and gas; and

 

   

potential acceleration of development of alternative fuels.

Historically, the markets for oil and gas have been volatile and are likely to continue to be volatile. Spending on exploration and production activities by large oil and gas companies has a significant impact on the activity levels of pipeline construction services.

In addition, demand for pipeline construction services may be affected by the costs of energy exploration and constructing energy infrastructure projects. For example, while high oil and gas prices may increase oil and gas exploration, production and transportation activity, high demand for equipment, materials and labor required for such projects may increase the costs of such projects and dampen demand for our services. Furthermore, increased costs for raw materials such as steel and other commodities may make some projects uneconomical despite robust oil and gas prices, thus reducing demand for our pipeline construction services. A decrease in demand for our pipeline construction services could materially and adversely affect our results of operations, cash flows and liquidity.

Legislative actions and incentives relating to electric power and renewable energy may fail to result in increased demand for our services.

While we believe the Energy Policy Act of 2005 (the “Energy Act”) will provide opportunities in the industries we serve, implementation of the Energy Act is still subject to considerable fiscal and regulatory uncertainty. Regulations implementing the components of the Energy Act that may affect demand for our services remain, in some cases, subject to review in various federal courts. In one such case, decided in February 2009, a federal court of appeals vacated FERC’s interpretation of the scope of its backstop siting authority. Accordingly, the effect of these regulations, once finally implemented, is uncertain. As a result, the Energy Act may not result in increased spending on electric power transmission infrastructure. Continued uncertainty regarding the implementation of the Energy Act may result in slower than anticipated growth in demand for our services.

Changes to renewable portfolio standards could, and decreased demand for renewable energy projects would, negatively impact our results of operations, cash flows and liquidity.

A portion of our business provides construction and/or installation services to owners and operators of wind power, solar power and other renewable energy facilities. The development of wind, solar and other renewable energy facilities is highly dependent upon federal production tax credits associated with the ARRA and the existence of renewable portfolio standards and other state incentives. Renewable portfolio standards are state specific statutory provisions requiring that electric utilities generate a certain amount of electricity from renewable energy sources or devote a certain portion of operational/development capacity to renewable energy sources. Additionally, certified renewable energy generators earn certificates for every unit of electricity they produce and can sell these along with their electricity to supply companies. These standards have spurred growth in the wind and renewable energy industry and a corresponding increase in demand for renewable energy infrastructure construction services. Currently, 36 states as well as the District of Columbia and Puerto Rico have adopted renewable portfolio standards or goals. Elimination of, or changes to, existing renewable portfolio standards or similar environmental policies may negatively affect demand for our services.

Additionally, renewable energy is generally more expensive to produce and may require additional power generation sources as backup. The locations of renewable energy projects are often remote and are not viable unless connectivity to the grid to transport the power to demand centers is economically feasible. Furthermore, funding for renewable energy initiatives may not be available. These factors could result in fewer renewable energy projects than anticipated or a delay in the timing of construction of these projects and the related infrastructure, which would negatively affect demand for our services.

The impact of the American Recovery and Reinvestment Act of 2009 is uncertain.

The continuing economic downturn, coupled with a lack of available capital, resulted in a tremendous amount of uncertainty, with numerous renewable energy projects being delayed or canceled. While we believe that the ARRA, which was enacted into law in February 2009, should aid renewable energy, electrical transmission and rural broadband market opportunities, the extent to which it will result in future revenues is uncertain. We cannot predict when programs under the ARRA will be implemented, or the timing and scope of

 

17


Table of Contents

investments to be made under these programs. Investments for renewable energy, electric power infrastructure rural broadband facilities under ARRA programs may not occur, may be less than anticipated or may be delayed, which would negatively impact demand for our services.

Additionally, the tax incentives provided by the ARRA have a finite duration. Currently, the election to claim the investment tax credit in lieu of the production tax credit is only available for qualified wind facilities placed in service from 2009 to December 31, 2012; the U.S. Treasury grant program will only be applicable to wind and solar projects placed in service in 2010 or 2011 (or after 2011 as long as construction begins in 2010 or 2011 and is completed before the termination date of the credit otherwise available for the property); and the production tax credit is scheduled to expire on December 31, 2012 and will not be available for energy generated from wind facilities placed in service after that date unless the credit program is extended or renewed. Whether the investment tax credit or U.S. Treasury grant program will be effective for wind, solar or other renewable energy projects is uncertain, as are any future efforts to extend or renew the production tax credit, the investment tax credit, and/or the U.S. Treasury grant program. Furthermore, the provisions regarding any extension or renewal may not be as favorable as those that currently exist. In addition, we cannot assure you that any extension or renewal of the production tax credit, the investment tax credit, and/or the U.S. Treasury grant program would be enacted prior to its expiration or, if allowed to expire, that any extension or renewal enacted thereafter would be enacted with retroactive effect. We also cannot assure you that the tax laws providing for accelerated and bonus depreciation with respect to wind or solar energy generation assets will not be modified, amended or repealed in the future. If the investment tax credit or the U.S. Treasury grant program are not effective or if the federal production tax credit is not extended or renewed, or is extended or renewed at a lower rate, the ability of our customers to obtain financing for these projects may be impaired or eliminated. In addition, changes to, or ineffectiveness of, the ARRA incentives could cause wind and solar farms to be less profitable, thereby potentially reducing demand for our wind and solar farm infrastructure construction services. Our revenue and results of operations could be materially adversely affected if demand for our services or the tax incentives were reduced.

Many of our customers are highly regulated and the addition of new regulations or changes to existing regulations may adversely impact their demand for our specialty contracting services and the profitability of those services.

Many of our communications customers are regulated by the FCC, and our energy customers are regulated by FERC. In addition, our utility customers are regulated by state public utility commissions. These agencies may interpret the application of their regulations in a manner that is different than the way such regulations are currently interpreted and may impose additional regulations. If existing or new regulations have an adverse affect on our customers and adversely impact the profitability of the services they provide, demand for our specialty contracting services may be reduced.

Our business may be affected by difficult work sites and environments, which could cause delays and result in additional costs.

We perform work under a variety of conditions, including, but not limited to, difficult and hard to reach terrain and difficult site conditions. Performing work under such conditions can result in project delays or cancellations, potentially causing us to incur additional, unanticipated costs, reductions in revenues or the payment of liquidated damages. In addition, some of our contracts require that we assume the risk should actual site conditions vary from those expected.

Some of our projects involve challenging engineering, procurement and construction phases that may occur over extended time periods, sometimes over several years. We may encounter difficulties in engineering, delays in designs or materials provided by the customer or a third party, equipment and material delivery delays, schedule changes, delays from customer failure to timely obtain rights-of-way, weather-related delays, delays by subcontractors in completing their portion of the project and other factors, some of which are beyond our control, but which impact our ability to complete a project within the original delivery schedule. In some cases, delays and additional costs may be substantial, and we may be required to cancel a project and/or compensate the customer for the delay. We may not be able to recover any of such costs. Any such delays or cancellations, defects or errors or other failures to meet customer expectations could result in damage claims substantially in excess of the revenue associated with a project. Delays or cancellations could also negatively impact our reputation or relationships with our customers, which could adversely affect our ability to secure new contracts.

Our failure to comply with environmental laws could result in significant liabilities.

Some of the work we perform is in underground environments. If the field location maps supplied to us are not accurate, or if objects are present in the soil that are not indicated on the field location maps, our underground work could strike objects in the soil containing pollutants and result in a rupture and discharge of pollutants. In such a case, we may be liable for fines and damages.

We own and lease several facilities at which we store our equipment. Some of these facilities contain fuel storage tanks which may be above or below ground. If these tanks were to leak, we could be responsible for the cost of remediation as well as potential fines. Additionally, we sometimes perform directional drilling operations below certain environmentally sensitive terrains and water bodies. Due to the inconsistent nature of the terrain and water bodies, it is possible that such directional drilling may cause a surface fracture releasing subsurface materials. These releases may contain contaminants in excess of amounts permitted by law, potentially exposing us to remediation costs and fines. In addition, new environmental laws and regulations, stricter enforcement of existing laws and regulations, the discovery of previously unknown contamination or leaks, or the imposition of new clean-up requirements could require us to incur significant costs or become the basis for new or increased liabilities that could have a material negative impact on our results of operations, cash flows and liquidity.

 

18


Table of Contents

Our business is subject to hazards that could result in substantial liabilities and weaken our financial condition.

Construction projects undertaken by us expose our employees to electrical lines, pipelines carrying potentially explosive materials, heavy equipment, mechanical failures, transportation accidents, adverse weather conditions and the risk of damage to equipment and property. These hazards can cause personal injuries and loss of life, severe damage to or destruction of property and equipment and other consequential damages and could lead to suspension of operations and large damage claims which could, in some cases, substantially exceed the amount we charge for the associated services. In addition, if serious accidents or fatalities occur, or our safety records were to deteriorate, we may be restricted from bidding on certain work and obtaining other new contracts and certain existing contracts could be terminated. Our safety processes and procedures are monitored by various agencies and rating bureaus. See Risk Factors – “Our failure to comply with the regulations of the U.S. Occupational Safety and Health Administration, the U.S. Department of Transportation and other state and local agencies that oversee transportation and safety compliance could reduce our revenue, profitability and liquidity.” The occurrence of accidents in our business could result in significant liabilities, employee turnover, increase the costs of our projects, or harm our ability to perform under our contracts or enter into new contracts with customers, which could materially reduce our revenue, profitability and liquidity.

Our operations may impact the environment or cause exposure to hazardous substances, and our properties may have environmental contamination, which could result in material liabilities.

Our operations are subject to various environmental laws and regulations, including those dealing with the handling and disposal of waste products, polychlorinated biphenyls (“PCBs”), fuel storage and air quality. Certain of our current and historical construction operations have used hazardous materials and, to the extent that such materials are not properly stored, contained or recycled, they could become hazardous waste. Additionally, some of our contracts require that we assume the environmental risk of site conditions and require that we indemnify our customers for any damages, including environmental damages incurred in connection with our projects. We may be subject to claims under various environmental laws and regulations federal and state statutes and/or common law doctrines for toxic torts and other damages, as well as for natural resource damages and the investigation and clean up of soil, surface water, groundwater, and other media under laws such as the Comprehensive Environmental Response, Compensation, and Liability Act. Such claims may arise, for example, out of current or former conditions at project sites, current or former properties owned or leased by us, and contaminated sites that have always been owned or operated by third parties. Liability may be imposed without regard to fault and may be strict, joint and several, such that we may be held responsible for more than our share of any contamination or other damages, or even for the entire share, and may be unable to obtain reimbursement from the parties causing the contamination.

Our failure to comply with the regulations of the U.S. Occupational Safety and Health Administration, the U.S. Department of Transportation and other state and local agencies that oversee transportation and safety compliance could reduce our revenue, profitability and liquidity.

The Occupational Safety and Health Act of 1970, as amended, or OSHA, establishes certain employer responsibilities, including maintenance of a workplace free of recognized hazards likely to cause death or serious injury, compliance with standards promulgated by the Occupational Safety and Health Administration and various recordkeeping, disclosure and procedural requirements. Various standards, including standards for notices of hazards and safety in excavation and demolition work may apply to our operations. We have incurred, and will continue to incur, capital and operating expenditures and other costs in the ordinary course of business in complying with OSHA and other state and local laws and regulations, and could incur penalties and fines in the future, including in extreme cases, criminal sanctions.

While we have invested, and will continue to invest, substantial resources in occupational health and safety programs, our industry involves a high degree of operational risk, and there can be no assurance that we will avoid significant liability exposure. Although we have taken what are believed to be appropriate precautions, we have suffered employee injuries and fatalities in the past and may suffer additional injuries or fatalities in the future. Serious accidents of this nature may subject us to substantial penalties, civil litigation or criminal prosecution. Personal injury claims for damages, including for bodily injury or loss of life, could result in substantial costs and liabilities, which could materially and adversely affect our financial condition, results of operations or cash flows. In addition, if our safety record were to substantially deteriorate, or if we suffered substantial penalties or criminal prosecution for violation of health and safety regulations, customers could cancel existing contracts and not award future business to us, which could materially adversely affect our liquidity, cash flows and results of operations.

We have, from time to time, received notice from the U.S. Department of Transportation that our motor carrier operations will be monitored and that the failure to improve our safety performance could result in suspension or revocation of vehicle registration privileges. If we were not able to successfully resolve these issues, our ability to service our customers could be damaged, which could lead to a material adverse effect on our results of operations, cash flows and liquidity.

 

19


Table of Contents

Risks associated with operating in international markets could restrict our ability to expand globally and harm our business and prospects, and we could be adversely affected by our failure to comply with the laws applicable to our foreign activities, including the U.S. Foreign Corrupt Practices Act and other similar worldwide anti-bribery laws.

We derived 3% of our revenue from international markets for the year ended December 31, 2011, and we may further expand the volume of services we provide internationally. Our international operations are presently conducted primarily in Canada, Latin America and the Caribbean, but we have performed work in various other foreign countries and revenues derived from, or the number of countries in which we operate, could expand over the next few years. Economic conditions, including those resulting from wars, civil unrest, acts of terrorism and other conflicts or volatility in the global markets, may adversely affect our customers, their demand for our services and their ability to pay for our services. In addition, there are numerous risks inherent in conducting our business internationally, including, but not limited to, potential instability in international markets, changes in regulatory requirements applicable to international operations, foreign currency fluctuations, exchange controls and other limits on our ability to repatriate earnings, political, economic and social conditions in foreign countries and complex U.S. and foreign laws and treaties, including tax laws and the U.S. Foreign Corrupt Practices Act (the “FCPA”). These risks could restrict our ability to provide services to international customers or to operate our international business profitably, and our overall business and results of operations could be negatively affected by our foreign activities.

The FCPA and similar anti-bribery laws in other jurisdictions prohibit U.S.-based companies and their intermediaries from making improper payments for the purpose of obtaining or retaining business. We pursue opportunities in certain parts of the world that experience government corruption to some degree, and, in certain circumstances, compliance with anti-bribery laws may conflict with local customs and practices. Our policies mandate compliance with these anti-bribery laws. Further, we require our subcontractors, agents and others who work for us or on our behalf to comply with the FCPA and other anti-bribery laws. Although we have policies and procedures designed to ensure that we, our employees and our agents comply with the FCPA and other anti-bribery laws, there is no assurance that such policies or procedures will protect us against liability under the FCPA or other laws for actions taken by our agents, employees and intermediaries. If we are found to be liable for FCPA violations (either due to our own acts or our inadvertence, or due to the acts or inadvertence of others), we could suffer from severe criminal or civil penalties or other sanctions, which could have a material adverse effect on our reputation, business, results of operations or cash flows. In addition, detecting, investigating, and resolving actual or alleged FCPA violations is expensive and can consume significant time and attention of our senior management.

Our subcontractors may fail to satisfy their obligations to us or other parties, or we may be unable to maintain these relationships, either of which may have a material adverse effect on our results of operations, cash flows and liquidity.

We depend on subcontractors to complete certain work on some of our projects. There is a risk that we may have disputes with subcontractors arising from, among other things, the quality and timeliness of work performed by the subcontractor, customer concerns about the subcontractor or our failure to extend existing task orders or issue new task orders under a subcontract. In addition, if any of our subcontractors fail to deliver on a timely basis the agreed-upon supplies and/or perform the agreed-upon services, then our ability to fulfill our obligations as a prime contractor may be jeopardized. In addition, the absence of qualified subcontractors with whom we have a satisfactory relationship could adversely affect the quality of our service and our ability to perform under some of our contracts. Any of these factors may have a material adverse effect on our results of operations, cash flows and liquidity.

We may choose, or be required, to pay our subcontractors even if our customers do not pay, or delay paying us for the related services.

We use subcontractors to perform portions of our services and to manage work flow. In some cases, we pay our subcontractors before our customers pay us for the related services. If we choose, or are required, to pay our subcontractors for work performed for customers who fail to pay, or delay paying us for the related work, we could experience a material decrease in profitability and liquidity.

Increases in the costs of fuel could reduce our operating margins.

The price of fuel needed to run our vehicles and equipment is unpredictable and fluctuates based on events outside our control, including geopolitical developments, supply and demand for oil and gas, actions by the OPEC and other oil and gas producers, war and unrest in oil producing countries, regional production patterns and environmental concerns. Most of our contracts do not allow us to adjust our pricing. Accordingly, any increase in fuel costs could materially reduce our profitability and liquidity.

Our profitability and liquidity could decline if certain customers reduce the amounts they pay for our services or if our customers are unable to pay for our services.

In the past, we incurred significant losses after a number of customers filed for bankruptcy or experienced financial difficulties following a general economic downturn, in which certain industry factors worsened the impact of the overall economic downturn on those customers. In 2011, we recorded $2.0 million of provisions for bad debts and as of December 31, 2011, our allowance for uncollectible accounts totaled $7.7 million. As of December 31, 2011, we had $2.6 million of receivables from customers undergoing bankruptcy reorganization. We do not anticipate difficulties in collecting the related receivables; however, we could experience losses if such customers are unable to pay us for our services.

 

20


Table of Contents

Our financial results are based, in part, upon estimates and assumptions that may differ from actual results.

In preparing our consolidated financial statements in conformity with accounting principles generally accepted in the United States (“U.S. GAAP”), a number of estimates and assumptions are made by management that affect the amounts reported in the consolidated financial statements. These estimates and assumptions must be made because certain information that is used in the preparation of our consolidated financial statements is either dependent on future events or cannot be calculated with a high degree of precision from data available. In some cases, these estimates are particularly uncertain and we must exercise significant judgment. Estimates are primarily used in our assessment of revenue recognition, provisions for contract losses, allowances for doubtful accounts, securities available for sale, valuation of goodwill and intangible assets, acquisition-related contingent consideration, certain convertible debt obligations, other reserves and accruals, impairment of assets, income taxes, accrued self-insured claims and litigation and contingencies. Actual results could differ materially from the estimates and assumptions that we use, which could have a material adverse effect on our results of operations, cash flows and liquidity.

We may incur goodwill impairment charges which could harm our profitability.

When we acquire a business, we record goodwill equal to the excess amount we pay for the business, including anticipated future liabilities and liabilities assumed, over the fair value of the acquired tangible and intangible assets of that business. As a result of our acquisitions, we have $925.8 million of goodwill and identifiable intangible assets recorded as of December 31, 2011. We expect to continue to record additions to goodwill in future periods in connection with completed acquisitions, including goodwill resulting from future earn-out payments for acquisitions completed prior to December 15, 2008.

We periodically review the carrying values of our goodwill and indefinite-lived intangible assets to determine whether such carrying values exceed their fair market values. We may incur impairment charges related to goodwill or indefinite-lived intangible assets in connection with any of our acquisitions in the future if the markets they serve or their businesses deteriorate.

We may incur restructuring or impairment charges, which could reduce our profitability.

From time to time we review our operations in an effort to improve profitability. We could incur charges in the future as a result of:

 

   

eliminating service offerings that no longer fit into our business strategy;

 

   

reducing or eliminating services or operations that do not produce adequate revenue or margin;

 

   

reducing costs of reporting units that need margin improvements; and

 

   

reviewing new business opportunities capable of utilizing our existing human and physical resources.

Any charges related to restructuring or impairment would be reflected as operating expenses and could materially reduce our profitability and liquidity.

Certain of our businesses have employees who are represented by a union or are subject to collective bargaining agreements; the unionized workforce and any related obligations could adversely affect our operations.

Certain of our employees are represented by labor unions and collective bargaining agreements. Although all of these agreements prohibit strikes and work stoppages, we cannot be certain that strikes or work stoppages will not occur in the future despite the terms of these agreements. Strikes or work stoppages would adversely impact relationships with our customers and could cause us to lose business and decrease our revenue. Additionally, as current agreements expire, the labor unions may not be able to negotiate extensions or replacements on terms favorable to their members, or at all, or avoid strikes, lockouts or other labor actions from time to time that may affect their members. Therefore, it cannot be assured that new agreements will be reached with employee labor unions as existing contracts expire, or on terms that we find desirable. Any labor action against us relating to failure to reach an agreement with employee labor unions could have a material adverse effect on our liquidity, cash flows and results of operations

Our participation in multi-employer pension plans may subject us to liabilities that could materially adversely affect our liquidity, cash flows and results of operations.

Substantially all of our union and collective bargaining agreements require us to participate with other companies in multi-employer pension plans. To the extent that those plans are underfunded defined benefit plans, the Employee Retirement Income Security Act of 1974, as amended by the Multi-Employer Pension Plan Amendments Act of 1980 (“ERISA”), may subject us to substantial liabilities if we withdraw from such multi-employer plans or if they are terminated. Under current law regarding multi-employer defined benefit plans, a plan’s termination, an employer’s voluntary partial or complete withdrawal from, or the mass withdrawal of all contributing employers from, an underfunded multi-employer defined benefit plan requires participating employers to make payments to the plan for their proportionate share of the multi-employer plan’s unfunded vested liabilities. Furthermore, the Pension Protection Act of 2006 added new funding rules

 

21


Table of Contents

generally applicable to plan years beginning after 2007 for multi-employer plans that are classified as “endangered,” “seriously endangered,” or “critical” status. If plans in which we participate are in critical status, benefit reductions may apply and/or we could be required to make additional contributions which could materially adversely affect our liquidity, cash flows and results of operations.

Based upon the information available to us from plan administrators as of December 31, 2011, several of the multi-employer pension plans in which we participate are underfunded. The Pension Protection Act requires that underfunded pension plans improve their funding ratios within prescribed intervals based on the level of their underfunding. In addition, if a multi-employer defined benefit plan fails to satisfy certain minimum funding requirements, the Internal Revenue Service may impose a nondeductible excise tax of 5% on the amount of the accumulated funding deficiency for those employers contributing to the fund. We have been notified that certain plans to which our subsidiaries contribute are in “critical” status and require additional contributions in the form of a surcharge on future benefit contributions required for future work performed by union employees covered by these plans. As a result, we expect our required contributions to these plans to increase in the future. The amount of additional funds we may be obligated to contribute in the future cannot be estimated, as such amounts will be based on future levels of work that require the specific use of those union employees covered by these plans, investment returns and the level of underfunding of such plans.

On November 15, 2011, we, along with other members of the Pipe Line Contractors Association (“PLCA”), voluntarily withdrew from the Central States Southeast and Southwest Areas Pension Fund (“Central States”), a defined benefit multi-employer pension plan. In connection with this withdrawal, we recorded a withdrawal liability of $6.4 million within costs of revenue. We withdrew from the Central States plan in order to mitigate our liability in connection with the plan, which is in critical status. The plan, however, has asserted that the PLCA members did not effect a withdrawal on November 15, 2011, although we believe that a legally effective withdrawal occurred as of this date and have recorded our withdrawal liability on this basis. If the plan were to prevail in its assertion and our withdrawal was deemed to have occurred after this date, however, then the amount of our withdrawal liability would be expected to increase. In addition, if this plan were to undergo a mass withdrawal, as defined by ERISA and the Pension Benefit Guaranty Corporation, within a three year time frame from the beginning of the calendar year from the point of our withdrawal, we could have additional liability.

Withdrawal liabilities, requirements to pay increased contributions, and/or excise taxes in connection with any of the multi-employer pension plans in which we participate could negatively impact our liquidity and results of operations. See Note 12 – Other Retirement Plans in the notes to consolidated financial statements for additional details.

If we are unable to attract and retain qualified managers and skilled employees, we will be unable to operate efficiently, which could reduce our revenue, profitability and liquidity.

Our business is labor intensive, and some of our operations experience a high rate of employee turnover. In addition, given the nature of the highly specialized work we perform, many of our employees are trained in and possess specialized technical skills. At times of low unemployment rates in the areas we serve, it can be difficult for us to find qualified and affordable personnel. We may be unable to hire and retain a sufficient skilled labor force necessary to support our operating requirements and growth strategy. Our labor expenses may increase as a result of a shortage in the supply of skilled personnel. We may also be forced to incur significant training expenses if we are unable to hire employees with the requisite skills. Additionally, our business is managed by a number of key executive and operational officers and is dependent upon retaining and recruiting qualified management. Labor shortages, increased labor or training costs, or the loss of key personnel could materially adversely affect our results of operations, cash flows and liquidity.

Our revolving credit facility, senior notes and senior convertible notes impose restrictions on us which may prevent us from engaging in transactions that might benefit us, including responding to changing business and economic conditions or securing additional financing, if needed.

At December 31, 2011, we had $365.0 million aggregate principal amount outstanding on our senior notes due 2017 and our senior convertible notes due 2014. We also have a revolving credit facility with $60.0 million outstanding as of December 31, 2011. Availability under our credit facility as of December 31, 2011 was approximately $450.0 million, net of outstanding standby letters of credit aggregating $90.0 million.

The terms of our indebtedness contain customary events of default and covenants that prohibit us from taking certain actions without satisfying certain financial tests or obtaining the consent of the lenders. The prohibited actions include, among other things:

 

   

buying back shares in excess of specified amounts;

 

   

making investments and acquisitions in excess of specified amounts;

 

   

incurring additional indebtedness in excess of specified amounts;

 

   

paying cash dividends;

 

   

creating certain liens against our assets;

 

22


Table of Contents
   

prepaying subordinated indebtedness;

 

   

engaging in certain mergers or combinations; and

 

   

engaging in transactions that would result in a “change of control” (as defined in the credit facility and the indenture governing our senior notes).

Additionally, certain provisions of our convertible notes could make it more expensive for a third party to acquire us or require us to repurchase the convertible notes for cash when required by the holders, including following a “fundamental change” (as defined in the indenture).

Our credit facility requires us to comply with a consolidated leverage ratio and a consolidated interest coverage ratio. Should we be unable to comply with the terms and covenants of our credit facility, we would be required to obtain further modifications of the facility or secure another source of financing to continue to operate our business. A default could also result in the acceleration of our obligations under the credit facility, or under the indenture relating to the senior notes and the indenture relating to our convertible notes. In addition, these covenants may prevent us from engaging in transactions that benefit us, including responding to changing business and economic conditions or securing additional financing, if needed. Our business is capital intensive and, to the extent we need additional financing, we may not be able to obtain such financing at all or on favorable terms, which may materially decrease our profitability, cash flows and liquidity.

Our inability to enforce non-competition agreements with former principals and key management of the businesses we acquire may adversely affect our operating results, cash flows and liquidity.

In connection with our acquisitions, we generally require that key management and the former principals of the businesses we acquire enter into non-competition agreements in our favor. The laws of each state differ concerning the enforceability of non-competition agreements. Generally, state courts will examine all of the facts and circumstances at the time a party seeks to enforce a non-competition agreement; consequently, we cannot predict with certainty whether, if challenged, a court will enforce any particular non-competition agreement. If one or more former principals or members of key management of the businesses we acquire leave and the courts refuse to enforce the non-compete agreement entered into by such person or persons, we might be subject to increased competition, which could materially and adversely affect our operating results, cash flows and liquidity.

Acquisitions involve risks that could result in a reduction of our operating results, cash flows and liquidity.

We have made, and in the future may continue to make strategic acquisitions or investments. However, we may not be able to identify suitable acquisition or strategic investment opportunities, or may be unable to obtain the consent of our lenders and therefore, may not be able to complete such acquisition or strategic investments. We may pay for acquisitions or strategic investments with our common stock or with convertible securities, which may dilute your investment in our common stock, or we may decide to pursue acquisitions with which investors may not agree. In connection with most of our acquisitions, we have also agreed to substantial earn-out arrangements. To the extent we defer the payment of the purchase price for any acquisition through a cash earn-out arrangement, it will reduce our cash flows in subsequent periods. In addition, acquisitions may expose us to operational challenges and risks, including:

 

   

the ability to profitably manage acquired businesses or successfully integrate the acquired business’ operations, financial reporting and accounting control systems into our business;

 

   

increased indebtedness and contingent purchase price obligations associated with an acquisition;

 

   

the ability to fund cash flow shortages that may occur if anticipated revenue is not realized or is delayed, whether by general economic or market conditions, or unforeseen internal difficulties;

 

   

the availability of funding sufficient to meet increased capital needs;

 

   

diversion of management’s attention; and

 

   

the ability to retain or hire qualified personnel required for expanded operations.

In addition, acquired companies may have liabilities that we failed, or were unable, to discover in the course of performing due diligence investigations. We cannot assure you that the indemnification granted to us by sellers of acquired companies will be sufficient in amount, scope or duration to fully offset the possible liabilities associated with businesses or properties we assume upon consummation of an acquisition. We may learn additional information about our acquired businesses that materially adversely affect us, such as unknown or contingent liabilities and liabilities related to compliance with applicable laws. Any such liabilities, individually or in the aggregate, could have a material adverse effect on our business.

 

23


Table of Contents

Failure to successfully manage the operational challenges and risks associated with, or resulting from, acquisitions could adversely affect our results of operations, cash flows and liquidity. Borrowings or issuances of convertible securities associated with these acquisitions may also result in higher levels of indebtedness which could impact our ability to service our debt within the scheduled repayment terms.

Claims, lawsuits and proceedings could reduce our profitability, cash flows and liquidity.

We are subject to various claims, lawsuits and proceedings which arise in the ordinary course of business. These actions may seek, among other things, compensation for alleged personal injury, workers’ compensation, employment discrimination, breach of contract, property damage, punitive damages, civil penalties or other losses, consequential damages, or injunctive or declaratory relief. In addition, pursuant to our service agreements, we generally indemnify our customers for claims related to the services we provide. Claimants may seek large damage awards and defending claims can involve significant costs. When appropriate, we establish reserves against these items that we believe to be adequate in light of current information, legal advice and professional indemnity insurance coverage, and we adjust such reserves from time to time according to case developments. If our reserves are inadequate, or if in the future our insurance coverage proves to be inadequate or unavailable, or if there is an increase in liabilities for which we self-insure, we could experience a reduction in our profitability and liquidity. An adverse determination on any such claim, lawsuit or proceeding could have a material adverse effect on our business, financial condition or results of operations. In addition, claims, lawsuits and proceedings may harm our reputation or divert management resources away from operating our business.

We have recorded unrealized losses to reduce the carrying value of certain auction rate securities we hold, and may incur additional impairment charges with respect to auction rate securities in future periods.

The continuing illiquidity of the auction rate securities market may affect our ability to liquidate certain auction rate securities that we classify as securities available for sale on our balance sheet. Our securities available for sale consist of auction rate securities, which represent interests in pools of student loans guaranteed by the U.S. government under the Federal Family Education Loan Program and a structured finance security. The structured finance security has an attached credit default swap under which the principal value of the structured finance security would be partially or fully forfeited at net default rates on the underlying corporate debt obligations ranging from 8% to 9%. The actual net default rate as of December 31, 2011 was estimated to be 5.56%. Both the structured finance security and the credit default swap are collateralized by investment grade credit-linked notes made up of floating rate international bank notes. All of our securities available for sale as of December 31, 2011, with a par value of $17.9 million and an estimated fair value and carrying amount of $13.6 million, had insufficient bidders at the scheduled rollover dates, indicating that immediate liquidity at par was unavailable. As of December 31, 2011, cumulative credit and other losses of $3.3 million have been recognized in connection with our structured finance security. Cumulative unrealized losses associated with our student loan auction rate securities totaled $1.0 million as of December 31, 2011.

Our valuation is sensitive to market conditions and management’s judgment and can change significantly based on the assumptions used. Factors that may impact our valuation include changes to credit ratings of the applicable securities, and for structured finance security, changes to the credit ratings of the underlying assets supporting the security as well as rates of default of the underlying assets, underlying collateral values, discount rates, counterparty risk and ongoing strength and quality of market credit and liquidity. We are uncertain as to when and if liquidity associated with these investments will improve, whether we will be able to exit these investments at their respective cost bases, or whether we will incur additional temporary or other-than-temporary losses as a result of these investments. As a result of this uncertainty, our auction rate securities are classified as a long-term assets as of December 31, 2011.

We have agreed to keep certain liabilities related to the state Department of Transportation related projects and assets that were sold in February 2007.

Effective February 1, 2007, we sold our state Department of Transportation related projects and assets. On January 24, 2008, we entered into a settlement agreement with the buyer of our state Department of Transportation projects and assets to settle previously disclosed warranty, indemnification and other claims primarily relating to work we had performed on the state Department of Transportation projects we sold. In connection with the settlement agreement, the parties also agreed to further amend and restate the Amended Asset Purchase Agreement effective as of January 24, 2008, which we refer to as the “Revised Amended Agreement.” In connection with the sale of our state Department of Transportation related projects and assets and the related settlement, we agreed to keep certain liabilities, mainly related to the cost to maintain and continue certain performance and payment bonds, certain obligations under leases between the parties and certain other litigation matters. We may also be unable to recover any losses we incur as a result of any third party claims to the extent any third parties seek payment from us directly and we are unable to recover such losses from the buyer pursuant to the indemnification obligations contained in the Revised Amended Agreement, including any losses resulting from creditor claims, in the event the buyer was financially unable to meet certain obligations.

Under the terms of the Revised Amended Agreement, the buyer is no longer required to issue a standby letter of credit in our favor to cover any remaining exposure related to our bonded obligations. Instead, pursuant to the terms of the settlement agreement, the buyer entered into indemnity agreements directly with certain surety bonding companies in connection with our bonded obligations. Therefore, if the buyer is unable to meet its contractual obligations, the surety bonding company can seek its remedies under the indemnity agreement. If the surety bonding company, however, pays the amounts due under the bonds, the surety bonding company will seek reimbursement of such

 

24


Table of Contents

payment from us. Accordingly, we may incur losses in the future related to these contingent liabilities if the buyer does not complete the bonded contracts and we are unable to recover such losses from the buyer pursuant to the indemnification provisions contained in the Revised Amended Agreement. The buyer of the Department of Transportation related projects and assets filed for bankruptcy protection in October 2009, which increased the likelihood that we could be required to assume certain obligations associated with these projects. As of December 31, 2011, we have completed the work associated with these projects and do not believe we have any further obligations thereunder. Should additional costs arise, we could incur future losses which could adversely affect our results of operations, cash flows and liquidity.

Risks Related to Our Company and Our Common Stock

We have a significant amount of debt. Our substantial indebtedness could adversely affect our business, financial condition and results of operations and our ability to meet our payment obligations.

We have a significant amount of debt and substantial debt service requirements. As of December 31, 2011, we had approximately $495 million of outstanding debt.

This level of debt could have significant consequences on our future operations, including:

 

   

making it more difficult for us to meet our payment and other obligations;

 

   

our failing to comply with the financial and other restrictive covenants contained in our debt agreements, which could trigger an event of default that results in all of our debt becoming immediately due and payable;

 

   

reducing the availability of our cash flow to fund working capital, capital expenditures, acquisitions or strategic investments and other general corporate requirements, and limiting our ability to obtain additional financing for these purposes;

 

   

subjecting us to the risk of increased sensitivity to interest rate increases on our indebtedness with variable interest rates, including borrowings under our credit facility;

 

   

preventing us from paying dividends;

 

   

limiting our flexibility in planning for, or reacting to, and increasing our vulnerability to changes in our business, the industry in which we operate and the general economy; and

 

   

placing us at a competitive disadvantage compared to our competitors that have less debt or are less leveraged.

Any of the above-listed factors could have an adverse effect on our business, financial condition and results of operations and our ability to meet our payment obligations.

Our ability to meet our payment and other obligations under our debt instruments depends on our ability to generate significant cash flow in the future. This, to some extent, is subject to general economic, financial, competitive, legislative and regulatory factors as well as other factors that are beyond our control. We cannot assure you that our business will generate cash flow from operations, or that future borrowings will be available to us under our credit facility or otherwise, in an amount sufficient to enable us to meet our payment obligations and to fund other liquidity needs. If we are not able to generate sufficient cash flow to service our debt obligations, we may need to refinance or restructure our debt, sell assets, reduce or delay capital investments, or seek to raise additional capital, and some of these activities may be on terms that are unfavorable or highly dilutive. Our ability to refinance our indebtedness will depend on the capital markets and our financial condition at such time. If we are unable to implement one or more of these alternatives, we may not be able to meet our payment obligations.

Currently, we intend to settle the principal amounts of our new senior convertible notes upon any conversion thereof in cash. As of December 31, 2011, there was outstanding $202.3 million aggregate principal amount of our new senior convertible notes. Notwithstanding our present intention to settle conversions of our new senior convertible notes in cash, we cannot assure you that we will be able to do so due to provisions in our credit facility, which restrict the repurchase or prepayment of certain unsecured indebtedness, including our senior notes due 2017 and senior convertible notes due 2014, unless the we have at least $50 million of remaining liquidity (as defined in the credit facility) after any such repurchase or prepayment. If we were required to settle conversions of our new senior convertible notes in accordance with our stated intent to settle principal amounts due in cash, and we were unable to do so with existing cash balances or through our credit facility, we could be required to obtain additional funding or settle such conversions in shares of our common stock, which would be dilutive to our existing shareholders. We cannot be certain that such funding would be available on terms acceptable to us, or at all.

 

25


Table of Contents

There may be future sales or other dilution of our equity, which may adversely affect the market price of our common stock. In connection with certain completed acquisitions and financing transactions, we have issued shares of our common stock or securities that are convertible into shares of our common stock, and in addition, we have the option to issue shares of our common stock instead of cash as consideration for future earn-out obligations. We may agree to issue additional securities in connection with other future acquisition or financing transactions; which, if issued, would dilute your share ownership and could lead to volatility in our common stock price.

We grow our business organically as well as through acquisitions. One method of acquiring companies or otherwise funding our corporate activities is through the issuance of additional equity securities. In connection with certain completed acquisitions, we have the option to issue shares of our common stock instead of cash for certain earn-out obligations. Such issuances could have the effect of diluting our earnings per share as well as our existing shareholders’ individual ownership percentages and could lead to volatility in our common stock price. Our Amended and Restated Articles of Incorporation provide that we may issue up to a total 145,000,000 shares of common stock, of which 80,568,864 shares were outstanding as of December 31, 2011.

We are not restricted from issuing additional common stock. The issuance of additional shares of our common stock upon conversion of any of our $215 million aggregate principal amount of convertible notes, in connection with future acquisitions or other issuances of our common stock or convertible securities, including outstanding options and warrants, or otherwise, will dilute the ownership interest of our common shareholders. Sales of a substantial number of shares of our common stock or other equity-related securities in the public market could depress the market price of our common stock and impair our ability to raise capital through the sale of additional equity or equity-linked securities. We cannot predict the effect that future sales of our common stock or other equity-related securities would have on the market price of our common stock.

A small number of our existing shareholders have the ability to influence major corporate decisions.

Jorge Mas, our Chairman, Jose Mas, our Chief Executive Officer and other members of the Mas family who are employed by MasTec, beneficially owned approximately 26.4% of the outstanding shares of our common stock as of December 31, 2011. Accordingly, they are in a position to influence:

 

   

the vote of most matters submitted to our shareholders, including any merger, consolidation or sale of all or substantially all of our assets;

 

   

the nomination of individuals to our Board of Directors; and

 

   

a change in our control.

These factors may discourage, delay or prevent a takeover attempt that shareholders might consider in their best interests or that might result in shareholders receiving a premium for their common stock.

The market price of our common stock has been, and may continue to be, highly volatile.

During the three years ended December 31, 2011, our common stock fluctuated from a high of $22.99 per share to a low of $9.03 per share. We may continue to experience significant volatility in the market price of our common stock. Numerous factors could have a significant effect on the price of our common stock, including:

 

   

announcements of fluctuations in our operating results or the operating results of one of our competitors;

 

   

future sales of our common stock or other securities, including any shares issued in connection with earn-out obligations for any past or future acquisition;

 

   

announcements by us or one of our competitors of new or terminated customers or new, amended or terminated contracts;

 

   

market conditions for providers of services to communications, utilities and government customers;

 

   

conversions or anticipated conversions of our senior convertible notes, or any sales in the public market of any of our common stock issuable upon such conversion;

 

   

changes in recommendations or earnings estimates by securities analysts; and

 

   

announcements of acquisitions by us or one of our competitors.

In addition, the stock market has experienced significant price and volume fluctuations in recent years, which have sometimes been unrelated or disproportionate to operating performance. The market price for our common stock has been volatile, and such volatility could cause the market price of our common stock to decrease and could cause shareholders to lose some or all of their investment in our common stock.

 

26


Table of Contents

Our articles of incorporation and certain provisions of Florida law contain anti-takeover provisions that may make it more difficult to effect a change in our control.

Certain provisions of our articles of incorporation, by-laws and the Florida Business Corporation Act could delay or prevent an acquisition or change in control and the replacement of our incumbent directors and management, even if doing so might be beneficial to our shareholders by providing them with the opportunity to sell their shares possibly at a premium over the then market price of our common stock. For example, our Board of Directors is divided into three classes. At any annual meeting of our shareholders, our shareholders only have the right to appoint approximately one-third of the directors on our Board of Directors. Consequently, it will take at least two annual shareholder meetings to effect a change in control of our Board of Directors, which may discourage hostile takeover bids. In addition, our articles of incorporation authorize our Board of Directors, without further shareholder approval, to issue preferred stock. The issuance of preferred stock could also dilute the voting power of holders of our common stock, including the granting of voting control to others, which could delay or prevent an acquisition or change in control.

 

ITEM 1B. UNRESOLVED STAFF COMMENTS

Not applicable.

 

ITEM 2. PROPERTIES

Our corporate headquarters is a 35,000 square foot leased facility located in Coral Gables, Florida.

As of December 31, 2011, our operations were conducted from more than 400 locations primarily within the United States and Canada, and, to a lesser extent, Latin America, including Puerto Rico, Panama and Mexico. None of these facilities is material to our operations because most of our services are performed on customers’ premises or on public rights of way and suitable alternative locations are available in substantially all areas where we currently conduct business.

We also own property and equipment that had a net book value of approximately $267 million as of December 31, 2011. This property and equipment includes land, buildings, vans, trucks, tractors, trailers, bucket trucks, backhoes, bulldozers, directional boring machines, digger derricks, cranes, networks, computers, computer software, office and other equipment. Our equipment is acquired from various third-party vendors, none of which we depend upon, and we did not experience any difficulties in obtaining desired equipment in 2011.

 

ITEM 3. LEGAL PROCEEDINGS

Legacy Litigation

The material set forth in Note 16 – Commitments and Contingencies in the notes to the consolidated financial statements in Item 8 of this Annual Report on Form 10-K is incorporated herein by reference.

 

ITEM 4. MINE SAFETY DISCLOSURES

Not applicable.

PART II

 

ITEM 5. MARKET FOR THE REGISTRANT’S COMMON EQUITY, RELATED SHAREHOLDER MATTERS AND ISSUER PURCHASES OF EQUITY SECURITIES

Market Information

Our common stock is listed on the New York Stock Exchange under the symbol “MTZ.” The following table sets forth, for the quarters indicated, the high and low sale prices of our common stock, as reported by the New York Stock Exchange.

 

     For the Years Ended December 31,  
     2011      2010  
     High      Low      High      Low  

First Quarter

   $ 20.85       $ 14.15       $ 13.92       $ 11.73   

Second Quarter

   $ 22.99       $ 17.36       $ 13.24       $ 9.33   

Third Quarter

   $ 22.20       $ 16.68       $ 11.37       $ 9.26   

Fourth Quarter

   $ 22.00       $ 13.95       $ 15.48       $ 10.04   

 

27


Table of Contents

Holders. As of February 27, 2012, there were 4,240 shareholders of record of our common stock.

Dividends. We have never paid any cash dividends and do not anticipate paying any cash dividends in the foreseeable future. We intend to retain any future earnings for reinvestment. Our Board of Directors will make any future determination as to the payment of dividends at its discretion, and this determination will depend upon our operating results, financial condition and capital requirements, general business conditions and such other factors that the Board of Directors considers relevant. In addition, our credit agreements prohibit us from paying cash dividends or making other distributions of our common stock without prior consent of the lender. The indenture governing our senior notes also contains covenants that restrict our ability to make certain payments including the payment of dividends. See Item 7. “Management’s Discussion and Analysis of Financial Condition and Results of Operations – Financial Condition, Liquidity and Capital Resources.”

Issuer Purchases of Equity Securities. During the fourth quarter of 2011, our Board of Directors authorized the repurchase of up to $150 million of MasTec common stock under a stock repurchase program. During the year ended 2011, we repurchased 4,593,663 shares of MasTec common stock at an average price of approximately $16.33 per share. Under the share repurchase program, shares may be repurchased from time to time in open market transactions or in privately-negotiated transactions in accordance with applicable federal securities laws. The timing and amount of any repurchases will be based on evaluation of market conditions, share price and other factors. The stock repurchase program expires one year from the date of authorization and may be modified or suspended at any time at our discretion. Stock repurchases will be funded with available cash or with availability under our credit facility.

The following table provides information about repurchases of our common stock during the three month period ended December 31, 2011:

 

Period

  Total Number
of Shares
Purchased (1)(2)
    Average
Price Paid
per Share
    Total Number of Shares
Purchased as Part of
Publicly Announced
Program (3)
    Approximate Dollar
Value of Shares that May
Yet be Purchased under
the Program
 

October 1 through October 31

    67,569      $ 16.97        —          —     

November 1 through November 30

    4,032,298      $ 16.33        4,030,785      $ 6,064,589   

December 1 through December 31

    380,634      $ 15.93        380,634      $ 75,000,004   
 

 

 

     

 

 

   

Total

    4,480,501          4,411,419     
 

 

 

     

 

 

   

 

(1) Share repurchases for the three months ended December 31, 2011 include 1,513 shares of common stock withheld for income tax purposes in connection with shares issued to certain employees and directors under compensation and benefit programs and 4,478,988 shares of common stock repurchased by the Company.
(2) Except to the extent described in footnote 1 above with respect to common stock withheld for income purposes under compensation and benefit programs, all shares were acquired in open-market transactions.
(3) Purchased pursuant to the Company’s publicly announced share repurchase program, which was initially a $75 million program that was announced on November 7, 2011. The Company later increased the maximum aggregate dollar amount of shares that may be repurchased under this program from $75 million to $150 million and announced such increase on December 16, 2011. Unless extended by the Company at its discretion, this share repurchase program will expire on December 16, 2012.

Performance Graph

The performance graph below compares the cumulative total returns for our common stock with the cumulative total return (including reinvestment of dividends) of the Standard and Poor’s 500 Composite Stock Index (S&P 500), and with that of our Peer Group, comprised of Dycom Industries, Inc., MYR Group, Inc., Quanta Services, Inc. and Pike Electric, Inc. The graph assumes an investment of $100 in our common stock and in each of the respective indices, for the period from December 31, 2006 to December 31, 2011. The comparisons in the graph are based upon historical data and are not intended to forecasts or be indicative of, possible future performance of our common stock.

 

28


Table of Contents

The performance graph shall not be deemed incorporated by reference by any general statement incorporating by reference this annual report into any filing under the Securities Act of 1933 or the Securities Exchange Act of 1934 except to the extent we specifically incorporate this information by reference, and shall not otherwise be deemed filed under such acts.

LOGO

 

As of December 31

   2006      2007      2008      2009      2010      2011  

MasTec, Inc.

   $ 100.00       $ 88.13       $ 100.35       $ 108.32       $ 126.43       $ 150.52   

S&P 500

   $ 100.00       $ 105.49       $ 66.46       $ 84.05       $ 96.71       $ 98.75   

Peer Group

   $ 100.00       $ 127.31       $ 85.68       $ 90.23       $ 91.99       $ 100.04   

 

ITEM 6. SELECTED FINANCIAL DATA

The following table states our selected consolidated financial data, which has been derived from our audited consolidated financial statements. The table reflects our consolidated results of operations for the periods indicated. Our consolidated results of operations are not necessarily comparable from period to period due to the impact of acquisitions. See the Note 3 – Acquisitions and Other Investments in the notes to consolidated financial statements for further details. In 2007, we sold our then-existing Canadian operations as well as our state Department of Transportation related projects and assets, both of which are presented as discontinued operations in table below. No material discontinued operations activity was recorded during any of the three years in the period ended December 2011.

 

29


Table of Contents

The following selected financial data should be read together with our consolidated financial statements and notes thereto as well as Item 7. “Management’s Discussion and Analysis of Financial Condition and Results of Operations.”

 

$0,000.0 $0,000.0 $0,000.0 $0,000.0 $0,000.0
     Year Ended December 31,  
     2011     2010     2009      2008     2007  
     (in millions, except per share amounts)  

Statement of Operations Data

           

Revenue

   $ 3,009.0      $ 2,308.0      $ 1,623.5       $ 1,378.7      $ 1,037.8   

Costs of revenue, excluding depreciation and amortization

   $ 2,606.1      $ 1,938.9      $ 1,376.1       $ 1,179.2      $ 891.6   

Income from continuing operations before non-controlling interests

   $ 106.0      $ 90.4      $ 70.7       $ 66.6      $ 6.3   

Loss from discontinued operations, net of tax

   $ —        $ —        $ —         $ (0.8   $ (13.6

Net income (loss)

   $ 106.0      $ 90.4      $ 70.7       $ 65.8      $ (7.3

Net loss attributable to non-controlling interests

   $ (0.0   $ (0.1   $ —         $ —        $ —     

Net income (loss) attributable to MasTec

   $ 106.0      $ 90.5      $ 70.7       $ 65.8      $ (7.3

Basic net income (loss) per share attributable to MasTec:

           

Continuing operations

   $ 1.29      $ 1.19      $ 0.93       $ 0.98      $ 0.10   

Discontinued operations

   $ —        $ —        $ —         $ (0.01   $ (0.21

Total basic net income (loss) per share attributable to MasTec

   $ 1.29      $ 1.19      $ 0.93       $ 0.97      $ (0.11

Diluted net income (loss) per share attributable to MasTec:

           

Continuing operations

   $ 1.23      $ 1.05      $ 0.90       $ 0.97      $ 0.09   

Discontinued operations

   $ —        $ —        $ —         $ (0.01   $ (0.20

Total diluted net income (loss) per share attributable to MasTec

   $ 1.23      $ 1.05      $ 0.90       $ 0.96      $ (0.11

 

$0,000.0 $0,000.0 $0,000.0 $0,000.0 $0,000.0
     Year Ended December 31,  
     2011      2010      2009      2008      2007  
     (in millions)  

Balance Sheet Data

              

Working capital

   $ 242.3       $ 235.1       $ 202.5       $ 105.3       $ 163.8   

Property and equipment, net

   $ 266.6       $ 180.8       $ 198.8       $ 158.0       $ 81.9   

Total assets

   $ 2,081.1       $ 1,655.8       $ 1,382.2       $ 1,090.9       $ 710.7   

Total debt

   $ 494.9       $ 412.6       $ 438.4       $ 304.3       $ 163.0   

Total shareholders’ equity

   $ 811.2       $ 653.2       $ 528.2       $ 443.1       $ 314.6   

 

ITEM 7. MANAGEMENT’S DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION AND RESULTS OF OPERATIONS

The following discussion and analysis of our financial condition and results of operations should be read in conjunction with our historical consolidated financial statements and related notes thereto in Item 8. “Financial Statements and Supplementary Data.” The discussion below contains forward-looking statements that are based upon our current expectations and are subject to uncertainty and changes in circumstances. Actual results may differ materially from these expectations due to inaccurate assumptions and known or unknown risks and uncertainties, including those identified in “Cautionary Statement Regarding Forward-Looking Statements” and Item 1A. “Risk Factors.”

We begin with an overview of our business, recent developments and financial results, a discussion of economic, industry and market factors and a summary of our revenue producing activities and related costs, along with a discussion of key metrics our management team uses when evaluating our performance. This overview is followed by a summary of critical accounting policies and estimates that we believe are important to understanding the assumptions and judgments incorporated in our reported financial results as well as our 2012 outlook. We then provide a more detailed analysis of our results of operations, financial condition, liquidity and capital resources.

Business Overview

We are a leading infrastructure construction company operating mainly throughout North America across a range of industries. Our activities include, but are not limited to, the engineering, building, installation, maintenance and upgrade of energy, utility and communications infrastructure, including: electrical utility transmission and distribution, power generation, natural gas and petroleum pipeline infrastructure, wireless, wireline and satellite communication, wind farms, solar farms and other renewable energy, industrial infrastructure and water and sewer systems. Our customers are primarily in the utility, communications and government industries.

Including our predecessor companies, we have been in business for more than 80 years. We offer our services primarily under the MasTec service mark, and as of December 31, 2011, we had approximately 10,000 employees and more than 400 locations. We have consistently been ranked among the top specialty contractors by Engineering News-Record over the past five years.

 

30


Table of Contents

We serve a diversified domestic customer base, and our top ten customers include some of the leading communication and utility companies in the United States, including DIRECTV®, AT&T, El Paso Corporation, Energy Transfer Company, Talisman Energy, Mid-American Energy, Dominion Virginia Power, DCP Midstream, Spectra Energy and EQT Corporation. We have longstanding relationships with many customers and often provide services under multi-year master service agreements and other service agreements. Because our business is concentrated among relatively few major customers, our business could be negatively impacted if the amount of business we obtain from these customers is reduced, or if we complete the required work on projects and cannot replace them with similar projects. Revenue concentration information, as a percent of total consolidated revenue, is as follows:

 

     For the Years Ended December 31,  
     2011     2010     2009  

Revenue from top ten customers

     71     72     72

Revenue from specific customers:

      

DIRECTV®

     23     24     30

AT&T

     23     20     16

Our relationship with AT&T is primarily based upon master service agreements, other service agreements and construction/installation contracts for both AT&T’s wireless and wireline infrastructure businesses.

Our relationship with DIRECTV® is based upon two agreements to provide installation and maintenance services for DIRECTV® and, in support of the installation business, to provide marketing and sales services on behalf of DIRECTV®. Refer to Note 3 – Acquisitions and Other Investments in the notes to the consolidated financial statements contained in this annual report for additional information regarding our purchase option agreement with Red Ventures, which, if exercised, could reduce future revenues from DIRECTV®. Without DirectStar’s revenues from services provided to DIRECTV®, our DIRECTV® revenues would have been reduced from 23% to 19% of total consolidated revenues for the year ended December 31, 2011. DirectStar accounted for $148.5 million and $143.3 million of our revenues in 2011 and 2010, respectively. Based upon current discussions with Red Ventures, we currently anticipate that the sale of DirectStar will occur in the second quarter of 2012; however, we cannot provide any assurance that Red Ventures will exercise its option or that any sale will occur.

We have actively pursued a diversification and expansion strategy in recent years. This strategy has deepened our presence and expanded our service offerings in key markets, including wireless, natural gas and petroleum pipeline, electrical transmission, renewable energy and heavy industrial infrastructure, among others.

2011 Acquisitions. In April 2011, we acquired Fabcor TargetCo Ltd., (“Fabcor”) a Canadian natural gas and petroleum pipeline infrastructure construction company. Fabcor expands our energy infrastructure services within the Canadian market and allows us to participate in the significant opportunities anticipated in that market in the future. Additionally, in April 2011 we exercised our EC Source merger option and, effective May 2, 2011, acquired the remaining 67% membership interest in EC Source, a nationally recognized full-service engineering, procurement and construction service entity, focusing on deploying extra high voltage electrical transmission systems throughout North America. During the second quarter of 2011, we also acquired: Cam Communications, Inc., a company specializing in equipment construction and network services for telecommunications carriers; Halsted Communications, Ltd., an install-to-the-home contractor operating primarily in portions of New York, Pennsylvania, and New England, whose primary customer is DIRECTV®; and Optima Network Services, Inc., a wireless infrastructure services company headquartered in California. See Note 3 – Acquisitions and Other Investments in the notes to the consolidated financial statements for details of our second quarter 2011 acquisitions.

In addition to integration and growth opportunities associated with our recent acquisitions, we also seek opportunities to expand our geographic presence, capabilities and service offerings in traditional business areas, such as telecommunications and install-to-the-home services.

Overview of Financial Results

Overall, 2011 revenue grew to $3.0 billion, an increase of $700.9 million, or 30%, from the prior year. Acquisitions completed during the second quarter of 2011 contributed $265.3 million, or 9% of our 2011 revenues. Organic revenue of $2.7 billion grew by $435.7 million, or 19%, versus the same period in the prior year. Strong end-user demand for new technologies in the wireless and install-to-the-home industries, pipeline construction and increased levels of activity in energy transmission were key growth drivers. While overall revenue growth was strong, revenues in certain areas of our business were negatively impacted by general economic conditions and industry factors. Our renewable project revenues declined versus the prior year as a result of tightened access of our customers to project financing, changes to our customers’ capital spending plans and competitive pressure on pricing.

Net income and diluted earnings per share were $106.0 million and $1.23 per share, respectively, for the year ended December 31, 2011, representing an increase of $15.5 million and $0.18 per share, or 17% and 17%, respectively, versus 2010. Factors contributing to our 2011 results included revenue growth, as previously discussed, improved leveraging of general and administrative expenses as a percentage of revenue, partially offset by an increase in our costs of revenue as a percent of sales. Also impacting our 2011 results was a $29.0 million pre-tax gain on the remeasurement of our equity investment in EC Source, which was acquired in May 2011. The gain was recorded within other income (expense).

 

31


Table of Contents

Costs of revenue as a percent of sales increased from 84.0% in 2010 to 86.6% in 2011. The increase was driven by several factors, including new DirectStar commission arrangements effective in 2011 as well as lower margins on certain projects in the second half of 2011. Our pipeline projects in the northeastern part of the United States were negatively affected by adverse weather conditions. Severe flooding in the northeastern United States beginning in the third quarter of 2011 negatively impacted working conditions and decreased productivity and profitability on certain projects. The Marcellus shale basin of the northeastern United States had above average amounts of rainfall in the second half of 2011. An unusually wet summer, coupled with the effects of Hurricane Irene in August and Tropical Storm Lee in September, caused significant flooding conditions in this region. Wireless projects, for which revenue growth has been robust, have experienced higher costs of revenue due to certain growth-related project inefficiencies. While we were able to meet the increased levels of demand for wireless services, we incurred higher labor and other costs in order to complete certain projects. Costs of revenue on renewable projects were also higher in comparison to the prior year due in large part to lower utilization of certain costs as a result of decreased revenues, as discussed above. In addition, 2011 costs of revenue was negatively impacted by a $6.4 million charge related to our multi-employer pension plans. In November 2011, we voluntarily withdrew from one of the multi-employer pension plans in which we participate. See Note 12 – Other Retirement Plans and Note 16 – Commitments and Contingencies in the notes to the consolidated financial statements for additional details.

Diluted earnings per share was favorably impacted in 2011 by a lower diluted share count resulting from several recent transactions. Total diluted shares decreased by approximately 4.2 million shares, from 90.9 million shares in 2010 to 86.7 million shares in 2011. During the first quarter of 2011, we exchanged 94% of our original senior convertible notes issued in 2009 (the “Original Convertible Notes”) for new senior convertible notes (the “New Convertible Notes”) that have an optional physical (share), cash or combination settlement feature, resulting in 10.4 million fewer diluted shares outstanding as compared with 2010. In addition, our Board of Directors authorized a share repurchase program during the fourth quarter of 2011. We repurchased 4.6 million shares under this program, which reduced our 2011 diluted average share count by 0.6 million shares. These decreases were partially offset by the issuance of 5.1 million shares in connection with our EC Source business combination in May of 2011 and the issuance of 1.9 million shares in December 2010 in connection with a purchase agreement amendment for one of our historical acquisitions. See Note 2 – Earnings Per Share and Note 3 – Acquisitions and Other Investments in the notes to the consolidated financial statements for additional information.

Economic, Industry and Market Factors

Despite the results we achieved during 2011, we recognize that we continue to operate in a challenging business environment, as do our customers. We closely monitor the effect that changes in economic and market conditions may have on our customers. General economic conditions, as well as the highly competitive nature of our industry, have resulted in pricing pressure for the services we provide. Work is often awarded through a bidding process, where price is often a principal factor in the selection process. In the face of increased pricing pressure, we strive to maintain our profit margins through productivity improvements and cost reduction programs. Other market and industry factors, such as tightened access to capital for customers in the industries we serve and/or changes to our customers’ capital spending plans, can result, and have resulted, in decreased levels of demand in certain portions of our business, such as our renewables projects, which were negatively impacted by such trends in 2011. In addition, we operate in industries affected by market and regulatory impacts beyond our control. Changes in technology, tax and other incentives, renewable energy portfolio standards and new or changing regulatory requirements affecting the industries we serve can impact demand for our services. Fluctuations in market prices for oil, gas and other fuel sources can also impact demand for our pipeline and renewable energy construction services. While we actively monitor economic, industry and market factors affecting our business, we cannot predict the impact such factors may have on our future results of operations, liquidity and cash flows.

Impact of Seasonality and Cyclical Nature of Business

Our revenues and results of operations can be subject to seasonal and other variations. These variations are influenced by weather, customer spending patterns, bidding seasons, project schedules and timing, particularly for large non-recurring projects, and holidays. Typically, our revenues are lowest in the first quarter of the year because cold, snowy or wet conditions cause delays. Revenues in the second quarter are typically higher than in the first quarter, as some projects begin, but continued cold and wet weather can often impact second quarter productivity. The third and fourth quarters are typically the best of the year, as a greater number of projects are underway and weather is normally more accommodating to work on projects. In the fourth quarter, many projects tend to be completed by customers seeking to spend their capital budget before the end of the year, which generally has a positive impact on our revenues. However, the holiday season and inclement weather can cause delays, which could reduce revenues and increase costs on affected projects. Any quarter may be positively or negatively affected by out of the ordinary weather patterns, such as excessive rainfall or warm winter weather, making it difficult to predict quarterly revenue and margin variations. See “Overview of Results” above for discussion of the negative impact on our productivity and margins of severe flooding in the northeastern United States beginning in the third quarter of 2011.

 

32


Table of Contents

Additionally, our industry can be highly cyclical. Fluctuations in end-user demand within the industries we serve, or in the supply of services within those industries, can impact demand for our services. As a result, our business may be adversely affected by industry declines or by delays in new projects. Variations in project schedules or unanticipated changes in project schedules, in particular in connection with large construction and installation projects, can create fluctuations in revenues, which may adversely affect us in a given period. The financial condition of our customers and their access to capital; variations in project margins; regional, national and global economic and market conditions; regulatory or environmental influences; and acquisitions or strategic investments can also materially affect quarterly results. Accordingly, our operating results in any particular period may not be indicative of the results that can be expected for any other period.

Revenue

We provide engineering, building, installation, maintenance and upgrade services to our customers. The primary industries served by our customers are communications, utilities and government. Customer revenues by industry for the periods indicated were as follows (in millions):

 

     Year Ended December 31,  
     2011     2010     2009  

Communications

   $ 1,625.0         54   $ 1,221.5         53   $ 950.6         59

Utilities

     1,339.3         45     1,046.8         45     596.0         36

Government

     44.7         1     39.7         2     76.9         5
  

 

 

    

 

 

   

 

 

    

 

 

   

 

 

    

 

 

 
   $ 3,009.0         100   $ 2,308.0         100   $ 1,623.5         100
  

 

 

      

 

 

      

 

 

    

Approximately 60% of our revenue is derived from projects performed under master service and other service agreements, which are generally multi-year agreements. Certain of our master service agreements are exclusive up to a specified dollar amount per work order for each defined geographic area, but do not obligate our customers to undertake any large infrastructure projects or other work with us. Work performed under master service and other service agreements is typically generated through work orders, each of which is performed for a fixed fee. Services provided under these agreements range from engineering, project management and installation work to maintenance and upgrade services. Master service agreements and other service agreements are frequently awarded on a competitive bidding basis, although customers are sometimes willing to negotiate contract extensions beyond their original terms without re-bidding. Our master service and other service agreements have various terms, depending upon the nature of the services provided, and typically provide for termination on short or no advance notice.

The remainder of our work is generated pursuant to contracts for specific projects or jobs that may require the construction and installation of an entire infrastructure system or specified units within an infrastructure system. Customers are billed with varying frequency, generally monthly or upon attaining specific milestones. Such contracts generally include retainage provisions under which 2% to 15% of the contract price is withheld from us until the work has been completed and accepted by the customer.

Revenues by type of contract for the periods indicated were as follows (in millions):

 

     Year Ended December 31,  
     2011     2010     2009  

Master service and other service agreements

   $ 1,777.7         59   $ 1,266.3         55   $ 934.3         58

Installation/construction project agreements

     1,231.3         41     1,041.7         45     689.2         42
  

 

 

    

 

 

   

 

 

    

 

 

   

 

 

    

 

 

 
   $ 3,009.0         100   $ 2,308.0         100   $ 1,623.5         100
  

 

 

      

 

 

      

 

 

    

As shown in the table above, just over 40% of our 2011 revenues were from non-recurring, project specific work. Seasonality tends to have a greater impact on our non-recurring project revenues. The proportion of our revenues from non-recurring project work in any given quarter can fluctuate based upon our project mix. If we are not able to replace work from completed projects with new project work, we may not be able to maintain our current revenue levels, or our current level of capacity and resource utilization. We actively review our backlog of project work and take appropriate action to minimize such exposure.

Costs of Revenue

Costs of revenue consists principally of salaries, employee wages and benefits, including multi-employer pension plan withdrawal charges, subcontracted services, equipment rentals and repairs, fuel and other equipment expenses, material costs, parts and supplies, insurance and facilities expenses. Project margins are calculated by subtracting a project’s costs of revenue from project revenue. Project profitability and corresponding project margins will be reduced if actual costs to complete a project exceed original estimates on fixed price and installation/construction service agreements. Estimated losses on contracts are recognized immediately when estimated costs to complete a project exceed the remaining revenue to be received over the remainder of the contract. Factors impacting our costs of revenue, and costs of revenue as a percent of sales, include:

Revenue Mix. The mix of revenues derived from the projects we perform impacts overall project margins, as certain projects provide higher margin opportunities. Installation work is often obtained on a fixed price basis, while maintenance work is often performed under pre-established or time and materials pricing arrangements. Project margins for installation work may vary from project to project, and can be higher than maintenance and upgrade work due to the fact that fixed price contracts often have a higher level of risk than other types of project work. Changes in project mix between installation work and maintenance or upgrade services can impact our project margins in a given period. Additionally, the mix of project revenues by industry served can also have an impact on overall project margins, as project margin opportunities can vary by industry and over time.

 

33


Table of Contents

Seasonality, Weather and Geographic Mix. As discussed above, seasonal patterns can have a significant impact on project margins. Generally, business is slower at the beginning of the year. Adverse or favorable weather conditions can impact project margins in a given period. For example, extended periods of rain or snowfall can negatively impact revenues and project margins as a result of reduced productivity from projects being delayed or temporarily placed on hold. Conversely, in periods when weather remains dry and temperatures are accommodating, more work can be done, sometimes with less cost, which can favorably impact project margins. In addition, the mix of business conducted in different parts of the country can affect project margins due to geographic characteristics associated with the physical location where the work is being performed, such as mountainous or rocky terrain versus open terrain. Site conditions, including unforeseen underground conditions, can also impact project margins.

Performance Risk. Overall project margins may fluctuate due to the volume of work performed, project pricing, job productivity and crew productivity. Job productivity can be impacted by weather, geography, environmental or regulatory factors, customer decisions and crew productivity. Crew productivity can be influenced by factors including weather conditions and job terrain, such as whether project work is in an open or encumbered right of way.

Subcontracted Resources. Our use of subcontracted resources in a given period varies, based upon activity levels and the amount and location of existing in-house resources and capacity. Work that is subcontracted can yield lower project margins than self-perform work. As a result, changes in the mix of subcontracted versus self-perform work can impact our overall project margins.

Material versus Labor Costs. In many cases, our customers are responsible for supplying their own materials on projects; however, under certain contracts, we may agree to provide all or part of the required materials. Project margins are typically lower on projects where we furnish a significant amount of materials due to the fact that mark-ups on materials are generally lower than on labor costs. Therefore, increases in the percentage of work with significant materials requirements could decrease our overall project margins.

Insurance Costs. Project margins can also be impacted by insurance costs as additional claims arise and as circumstances and conditions of existing claims change. We maintain insurance policies subject to per claim deductibles of $1 million for our worker’s compensation policy and $2 million for our general liability and automobile liability policies. We also have employee healthcare benefit plans for our employees not subject to collective bargaining agreements, which are subject to annual per employee maximum losses of $0.4 million per year.

General and Administrative Expense

General and administrative expenses consist principally of compensation and benefit expenses, travel expenses and related costs for our finance, benefits and risk, legal, facilities, information services and executive personnel. General and administrative expenses also include outside professional and accounting fees, transaction expenses, expenses associated with information technology used in administration of the business and various forms of insurance.

Interest Expense, Net

Interest expense, net, consists of contractual interest expense on outstanding debt obligations, amortization of deferred financing costs, accretion associated with our New Convertible Notes, and other interest expense, such as line of credit and letter of credit fees, offset by interest earned on cash, cash equivalents and fixed income investments.

Other (Income) Expense, Net

Other (income) expense, net, consists primarily of gains or losses from sales of assets and investments, income or losses from equity method investments, gains or losses from foreign currency transactions, gains or losses from changes to estimated earn-outs accrued as a component of purchase price for recent acquisitions, and other-than-temporary impairment losses recognized in connection with our available for sale securities. Other (income) expense, net, also includes the non-cash gain on remeasurement of our equity investment in EC Source, which was acquired in the second quarter of 2011.

 

34


Table of Contents

Financial Metrics

Members of our senior management team regularly review key performance metrics and the status of operating activities within our business. These key performance indicators include:

 

   

revenue and profitability on an overall, reporting unit and individual project basis;

 

   

monthly, quarterly and annual changes in revenue and profitability on an overall, reporting unit and individual project basis;

 

   

revenues by customer, by industry and by contract type;

 

   

costs of revenue, general and administrative expenses, depreciation and amortization, tax and interest expense as a percentage of revenue;

 

   

earnings before interest, taxes, depreciation and amortization (“EBITDA”) and adjusted EBITDA, which is EBITDA excluding (i) the May 2011 gain on remeasurement of our investment in EC Source, and (ii) the $6.4 million charge we recorded in the fourth quarter of 2011 relating to our withdrawal from a multi-employer pension plan, as a percentage of revenue;

 

   

days sales and days payable outstanding;

 

   

interest and debt service coverage ratios;

 

   

liquidity and cash flows;

 

   

safety results and productivity; and

 

   

customer service metrics on an individual project basis.

Management analyzes this information periodically through operating reviews, which include detailed discussions of proposed investments in new business opportunities or property and equipment, integration efforts and cost reduction efforts. Measuring these key performance indicators is an important tool used by management to make operational decisions. These tools enable our management to make informed and timely decisions about the allocation of costs and resources, which we believe can help us improve our performance.

Critical Accounting Policies and Estimates

This discussion and analysis of our financial condition and results of operations is based upon our consolidated financial statements, which have been prepared in accordance with U.S. GAAP. The preparation of these financial statements requires us to make estimates and judgments that affect the amounts reported in our financial statements and the accompanying notes. On an on-going basis, we evaluate our estimates, including those related to revenue recognition, estimates to complete and provisions for contract losses, allowances for doubtful accounts, accrued self-insured claims, estimated fair values of goodwill and intangible assets, acquisition-related contingent consideration, investments in equity method investees, securities available for sale and certain convertible debt obligations, reserves and accruals, impairment of assets, income taxes and litigation and contingencies. We base our estimates on historical experience and on various other assumptions that we believe to be reasonable under the circumstances, the results of which form the basis of making judgments about the carrying values of assets and liabilities that are not readily apparent from other sources. As management estimates, by their nature, involve judgment regarding future uncertainties, actual results may differ from these estimates if conditions change or if certain key assumptions used in making these estimates ultimately prove to be materially incorrect.

We believe the following accounting policies are the most critical in the preparation of our consolidated financial statements as they are both important to the portrayal of our financial condition and they require significant or complex judgment and estimates on the part of management. Refer to Note 1 – Business, Basis of Presentation and Significant Accounting Policies in the notes to the consolidated financial statements for further description of our significant accounting policies.

Our critical accounting policies are reviewed frequently with the Audit Committee of the Board of Directors.

Revenue Recognition

We enter into various types of contracts, including unit price, time and materials, cost-plus and fixed price contracts. Under unit price contracts, we agree to perform work for a price per unit of work performed. Fixed price contracts provide for a fixed fee for an entire project, the final terms and prices of which can be subject to negotiation with the customer, as is customary in the industry. Work performed on a time and materials basis is billed based upon negotiated hourly rates plus material costs. Cost-plus contracts are based on actual costs incurred for materials, equipment and labor, plus an agreed upon markup. Although the terms of our contracts vary considerably, most are on either a unit price or a fixed price basis. We complete a substantial majority of our fixed price projects within one year, while we frequently provide maintenance, installation and repair work under unit price or fixed price master service or other service agreements that are renewable periodically.

 

35


Table of Contents

We recognize revenue on long-term construction contracts on a percentage of completion basis. Some of our long-term construction projects are pursuant to master service or other service agreements. Under fixed price contracts, revenues are recognized as work on the contract progresses using the cost-to-cost method. Under this method, revenue is recognized based on the percentage of total costs incurred to date in proportion to total estimated costs to complete the contract. Fixed price contracts generally include retainage provisions under which a percentage of the contract price is withheld until the project has been completed and the work has been accepted by our customer. For projects that are of a short-term nature, primarily under master service or other service agreements, revenue is recognized when units are completed or when the related services are performed.

Contract costs include all direct materials, labor and subcontract costs and those indirect costs related to contract performance, such as indirect labor, supplies, tools, repairs and the operational costs of capital equipment (excluding depreciation). Much of the materials associated with our work are customer-furnished and are therefore not included in contract revenues and costs. The cost estimation process is based on the professional knowledge and experience of our engineers, project managers and financial professionals. Changes in job performance, job conditions and final contract settlements are factors that influence management’s assessment of total contract value and the total estimated costs to complete those contracts and therefore, our profit recognition. Changes in these factors may result in revisions to costs and income, and their effects are recognized in the period in which the revisions are determined. Provisions for losses on uncompleted contracts are made in the period in which such losses are determined to be probable and the amount can be reasonably estimated.

We may incur costs subject to change orders, whether approved or unapproved by the customer, and/or claims related to certain contracts. We determine the probability that such costs will be recovered based upon evidence such as engineering studies and legal opinions, past practices with the customer, specific discussions, correspondence or preliminary negotiations with the customer. We treat project costs as a cost of contract performance in the period incurred if it is not probable that the costs will be recovered, or we defer costs and/or recognize revenue up to the amount of the related cost if it is probable that the contract price will be adjusted and can be reliably estimated.

Billings in excess of costs and estimated earnings on uncompleted contracts are classified as current liabilities. Costs and estimated earnings in excess of billings, or work in process, is classified within current assets for the majority of our projects. Work in process on contracts is based on work performed but not yet billed to customers as per individual contract terms.

Allowance for Doubtful Accounts

We maintain allowance for doubtful accounts for estimated losses resulting from the inability of our customers to make required payments. We analyze the collectibility of accounts receivable and the adequacy of the allowance for doubtful accounts on a regular basis, based on the aging of account balances, historical bad debt experience, customer concentrations, customer credit-worthiness, customer financial condition and credit reports, availability of mechanics’ and other liens, existence of payment bonds and other sources of payment and current economic trends. For reporting units where losses have occurred historically and are considered to be ordinary course, reserves are established for anticipated losses based on statistical analysis of the accounts receivable portfolio. For reporting units where historical losses have been immaterial, an increase in the allowance for doubtful accounts is recorded when it is probable a receivable is not collectible and the loss can be reasonably estimated. Amounts are written off against the allowance when deemed uncollectible. If our estimates of the collectibility of accounts receivable change, or should customers experience unanticipated financial difficulties, or if anticipated recoveries in existing bankruptcies or other work-out situations fail to materialize, adjustments to the allowance for doubtful accounts may be required, which could reduce our profitability and cash flows.

Our estimates for the allowance for doubtful accounts are subject to significant change during times of economic weakness or uncertainty in either the overall U.S. economy or within the industries we serve. To proactively manage accounts receivable aging and collections and evaluate the adequacy of our allowance for doubtful accounts, we continue to monitor the economic environment and its impact on our customers.

Goodwill and Intangible Assets

We perform our annual impairment review of goodwill and certain intangible assets with indefinite lives during the fourth quarter each year at the reporting unit level. Assets of acquired businesses and related goodwill are allocated to the corresponding reporting units. We identify our reporting units by assessing whether the components holding purchased assets, including goodwill and related assumed liabilities, have discrete financial information available. To the extent two or more components are deemed economically similar, those components are aggregated into a single reporting unit for purposes of our annual goodwill impairment review. Our reporting units are one level below our reportable segment.

Our reporting units sell and provide contracting services, including engineering, building, installation, maintenance and upgrade services, primarily by digging and drilling trenches and installing poles, pipe, towers, antennae, wire, and equipment. Many of our reporting units perform these services across multiple industries, including telecommunications, utilities and government, and on behalf of a variety of customers, some of which contract services from multiple reporting units.

 

36


Table of Contents

During the year ended December 31, 2011, we adopted ASU 2011-08, which permits an entity to first assess qualitative factors to determine whether it is more likely than not that the fair value of a reporting unit is less than its carrying amount as a basis for determining whether it is necessary to perform the traditional two-step goodwill impairment test. Based on this analysis, none of our reporting units were considered more likely than not to be impaired as of December 31, 2011. During each of the two years in the period ended December 31, 2010, management estimated the fair value of our reporting units using a discounted cash flow methodology, which incorporates five-year projections of revenues, operating costs and cash flows considering historical and anticipated future results, general economic and market conditions, as well as the impact of planned business and operational strategies. We applied a discounted cash flow technique utilizing a terminal value equal to 5.5 times year five EBITDA. The discount rate was estimated to be 8.5% per annum and represents our estimated cost of capital at the time of the analysis. A 100 basis point change in the discount rate would not have had a material impact on the results of the impairment analysis.

Based upon the most recent analyses performed, we determined that the estimated fair values of our reporting units substantially exceeded their carrying values. However, under ASU 2011-08, we are no longer required to perform a full quantitative analysis if our qualitative analysis concludes that it is more likely than not that the fair value of the reporting unit is greater than its carrying amount. Significant changes in the estimates used in our analysis could result in an impairment charge related to goodwill and/or intangible assets. In addition, we could record impairment losses in the future if profitability and cash flows of our reporting entities decline to the point where their carrying values exceeded their market values.

Business Combinations – Valuation of Acquired Assets and Liabilities

Allocations of purchase price for acquisitions are based on estimates of the fair value of consideration paid and the net assets acquired. Accounting for business combinations requires estimates and judgments as to expectations of future cash flows for acquired businesses and the allocation of those cash flows to identifiable tangible and intangible assets in determining the estimated fair values of assets acquired and liabilities assumed. The fair values assigned to tangible and intangible assets and liabilities, including contingent consideration, are based on management’s estimates and assumptions utilizing customary valuation procedures and techniques. See Note 5 – Fair Value of Financial Instruments in the notes to the consolidated financial statements for our policy on fair value estimates. Contingent consideration is measured at its estimated fair value as of the date of acquisition, with subsequent changes in fair value recorded in earnings as a component of other income or expense. If actual results differ significantly from the estimates and judgments used in determining the estimated fair values of assets and liabilities recorded as of the date of acquisition, these differences could result in a possible impairment of recorded assets, including intangible assets and goodwill, or require acceleration of amortization expense of finite-lived intangible assets.

Self-Insurance

We presently maintain insurance policies subject to per claim deductibles of $1 million for our workers’ compensation policy, $2 million for our general liability policy and $2 million for our automobile liability policy. We have excess umbrella coverage up to $100 million per claim and in the aggregate. We also maintain an insurance policy with respect to employee group health claims subject to annual per employee maximum losses of $0.4 million. Liabilities under these insurance programs are accrued based upon our estimate of the ultimate liability for claims reported and an estimate of claims incurred but not reported, with assistance from third-party actuaries. The present value of our self-insurance liabilities are reflected in our balance sheet as current and other non-current liabilities. The determination of such claims and expenses and the appropriateness of the related liability is reviewed and updated quarterly. However, insurance liabilities are difficult to assess and estimate due to unknown factors, including the severity of an injury, the determination of our liability in proportion to other parties and the number of incidents not reported. We continue to work with our insurance carriers to resolve claims quickly in an effort to reduce our exposure. We are also attempting to accelerate the claims process where possible so that amounts incurred can be reported rather than estimated. Accruals are based upon known facts and historical trends and we believe such accruals to be adequate. However, a change in experience or actuarial assumptions could nonetheless materially affect results of operations in a particular period.

Securities Available-for-Sale

Our securities available for sale consist of auction-rate securities, which represent interests in pools of student loans guaranteed by the U.S. government under the Federal Family Education Loan Program and a structured finance security. The structured finance security has an attached credit default swap under which the principal value of the structured finance security would be partially or fully forfeited at net default rates on the underlying corporate debt obligations ranging from 8% to 9% as of December 31, 2011. The actual net default rate as of December 31, 2011 is estimated to be 5.56%. Both the structured finance security and the credit default swap are collateralized by investment grade credit-linked notes made up of floating rate international bank notes.

Liquidity for auction rate securities was originally intended to be provided by an auction process that would reset the applicable interest rate at pre-determined intervals, usually every 7, 28 or 35 days. Due to disruptions in the credit markets beginning in 2008, these auctions have not had sufficient bidders to allow investors to complete a sale, indicating that immediate liquidity at par is unavailable. As a result, there was insufficient observable market data to determine the fair value of our auction rate securities as of December 31, 2011. Therefore, their respective fair values were estimated by an independent valuation firm, Houlihan Capital Advisors, LLC, using a probability-weighted discounted cash flow model. The model incorporates assumptions that market participants would use in their estimates of fair value,

 

37


Table of Contents

such as reset interest rates, final stated maturities, collateral values, credit quality and insurance, and applies the probabilities of either (a) a successful auction; (b) a failed auction; or (c) a default; at each auction. This valuation is sensitive to market conditions and our judgment and can change significantly based on the assumptions used. Factors that may impact the valuation include: changes to credit ratings of the securities and, for the structured finance securities, changes to the credit ratings of the underlying assets supporting the securities as well as rates of default of the underlying assets, underlying collateral values, discount rates, counterparty risk and ongoing strength and quality of market credit and liquidity.

Due to the liquidity issues associated with our auction-rate securities, they have been recorded at their fair value as long-term assets in our consolidated financial statements. Temporary unrealized holding gains and losses are recorded as a separate component of accumulated other comprehensive income (loss), net of applicable income taxes. Unrealized losses are charged against earnings when a decline in fair value is determined to be other-than-temporary. An impairment is considered to be other-than-temporary if an entity intends to sell a security, more likely than not will be required to sell a security before recovering its cost, or does not expect to recover a security’s entire amortized cost basis, even if there is no intent to sell the security.

We consider several factors in assessing whether a loss is other-than-temporary. These factors include, but are not limited to: the intent and more likely than not, the ability to hold a security for a period of time sufficient to allow for recovery of its fair value; the length of time a security is in an unrealized loss position; the extent to which fair value is less than cost; the financial condition and near term prospects of the issuer; changes to the credit ratings of securities, as well as their underlying assets; and, for our structured finance security, rates of default on the underlying portfolio of credit default swaps.

In assessing the expectation of recovering a security’s amortized cost basis, we perform an assessment of the present value of cash flows expected to be collected. If this assessment yields an amount less than the amortized cost basis of the security, even if the Company has the intent, and more likely than not, the ability to hold the securities, a credit loss is deemed to exist. The amount of an other-than-temporary impairment attributed to the credit losses is recognized in earnings, while the amount of an other-than-temporary impairment related to other factors is recognized in other comprehensive income, net of applicable deferred income taxes. We estimate credit losses associated with our auction rate securities using Level 3 inputs. Credit loss estimates are derived by comparing the estimated fair value of the securities, which are based on a number of factors, including estimated probabilities of default, with the value that would have been derived if the probability of default for the same securities were zero percent. The difference between the recorded fair value and the estimated fair value assuming a zero probability of default is considered the portion of total decline in fair value attributable to credit losses.

Structured Finance Auction Rate Securities. Following the sale of two of our three structured finance auction rate securities in the fourth quarter of 2010, we determined that we no longer met the criteria for intent to hold with respect to our remaining structured finance security. Accordingly, subsequent declines in this security’s cost basis have been recognized in earnings, whereas any increases will be recorded in other comprehensive income, net of applicable income taxes.

Student Loan Auction Rate Securities. During the second quarter of 2011, the issuer of one of our student loan auction rate securities redeemed its security at the security’s par value. We continue to have intent to hold, and more likely than not, will not be required to sell our remaining student loan auction rate securities until maturity or until their par value can be recovered. Temporary unrealized holding gains and losses are recorded as a separate component of accumulated other comprehensive income (loss), net of applicable income taxes.

See Note 6 – Securities Available for Sale in the notes to the consolidated financial statements for additional details.

Income Taxes

We record income taxes using the asset and liability method of accounting for deferred income taxes. Under this method, deferred tax assets and liabilities are recognized for the expected future tax consequence of temporary differences between the financial statement and income tax basis of our assets and liabilities. Income taxes are estimated in each of the jurisdictions in which we operate. This process involves estimating the tax exposure together with assessing temporary differences resulting from differing treatment of items, such as deferred revenue, for tax and accounting purposes. These differences result in deferred tax assets and liabilities, which are included within the consolidated balance sheet. The recording of a net deferred tax asset assumes the realization of such asset in the future. Otherwise, a valuation allowance must be recorded to reduce this asset to its net realizable value.

We consider future pretax income and ongoing prudent and feasible tax planning strategies in assessing the net realizable value of tax assets and the need for such a valuation allowance. In the event that we determine that we may not be able to realize all or part of the net deferred tax asset in the future, a valuation allowance for the deferred tax asset is charged against income in the period such determination is made. As of December 31, 2010, we had substantially utilized our net operating loss carryforwards for federal income tax purposes. In prior years, we released the valuation allowance that was previously established against domestic net operating losses. Based on our recent history of profitability and our forecasts for future periods, we determined that it is more likely than not that the state net operating loss carryforwards and other temporary differences would be realized. As of December 31, 2011 and 2010, we have valuation allowances aggregating $2.8 million and $5.6 million, respectively. These valuation allowances relate to foreign net operating losses and credit carryforwards that we believe may not be realized in future periods.

 

38


Table of Contents

In determining the provision for income taxes, we use an effective tax rate based on annual pre-tax income, permanent tax differences, statutory tax rates and tax planning opportunities in the various jurisdictions in which the Company operates. Significant factors that impact the annual effective tax rate include our assessment of certain tax matters, the location and amount of taxable earnings, changes in certain non-deductible expenses and expected credits. As of December 31, 2011, we have not made a provision for U.S. income taxes on unremitted foreign earnings because such earnings are intended to be indefinitely reinvested outside the U.S. Generally, such amounts become subject to U.S. taxation upon the remittance of dividends and certain other circumstances.

Our subsidiaries file income tax returns in numerous tax jurisdictions, including U.S. federal, most U.S. states and certain foreign jurisdictions. The statute of limitations varies by the various jurisdictions in which we operate. Our U.S. federal income tax returns for years ending on or after 2008 still remain open for examination. Although we believe our calculations for tax returns are correct and the positions taken thereon are reasonable, the final outcome of tax audits could be materially different from the resolution we currently anticipate, and those differences could result in significant costs or benefits to us.

Multi-Employer Pension Plans

We make contributions to certain union-administered multi-employer pension plans. Contributions are generally based on fixed amounts per hour per employee for employees covered under these plans. To the extent that those plans are underfunded, the Employee Retirement Income Security Act of 1974, as amended by the Multi-Employer Pension Plan Amendments Act of 1980, may subject us to substantial liabilities if we withdraw from such multi-employer plans or if they are terminated. In November 2011, we voluntarily withdrew from one of the multi-employer pension plans in which we participated and recorded a charge of $6.4 million within costs of revenue. Withdrawal liabilities under multi-employer pension plans are based on estimates of our proportionate share of the plan’s unfunded vested liability, as calculated by the plan’s actuaries, and represent our best estimate of such liabilities as of the time we record such withdrawal liabilities. Any changes in estimated withdrawal liabilities could materially affect our results of operations, cash flows and financial position in the period such changes occur. See Note 12 – Other Retirement Plans and Note 16 – Commitments and Contingencies for additional details.

Litigation and Contingencies

Litigation and contingencies are reflected in our consolidated financial statements based on our assessments, along with legal counsel, of the expected outcome of litigation proceedings or the expected resolution of the contingency. We accrue a liability for an estimated loss if the potential loss from any claim or legal proceeding is considered probable and the amount can be reasonably estimated. Significant judgment is required in both the determination of probability and the determination as to whether the amount of an exposure is reasonably estimable. Because of uncertainties related to these matters, accruals are based only on the information available at the time. As additional information becomes available, we reassess the potential liability related to our pending claims and litigation and may revise our estimates. Such revisions in estimates of potential liabilities could have a material impact on our results of operations and financial position.

See Note 16 – Commitments and Contingencies in the notes to the consolidated financial statements for discussion of current litigation matters.

2012 Outlook

We believe we have significant market opportunities in 2012 in six areas:

Wireless and Fiber Communications Network Upgrades – we believe wireless and fiber optic communication network upgrades will continue to grow in 2012 and that the major regional and rural telecommunications and other communications companies will continue to expand and enhance their capabilities in these areas, which could increase demand for our services. We continue to expand our capabilities in wireless infrastructure construction. Additionally, the ARRA has allocated $7.2 billion for the development of broadband facilities throughout the U.S and the expansion of broadband access into areas that are currently not served by high-speed data networks.

Petroleum, Natural Gas and Natural Gas Liquids Pipelines – we believe that demand for clean-burning, domestic natural gas will grow in order to reduce U.S. dependence on foreign energy sources. Additionally, we believe that the attractive pricing for petroleum and natural gas liquids will also increase drilling and the demand for pipelines transporting these products. With recent developments in drilling and completion technologies for oil and gas, we expect new North American producing fields to be developed and old fields’ productivity to be expanded significantly. We anticipate the resulting incremental production will provide increasing opportunities for our oil & gas gathering, gas compression, liquids pumping, oil & gas treatment, long-haul and mid-stream oil & gas and other liquids pipeline construction operations. We have made acquisitions in the last few years to expand our capabilities in these areas.

 

39


Table of Contents

Alternative and Renewable Energy Projects – we believe this market will grow in 2012 as developers seek to qualify for the expiring Federal section 1603 investment tax credits for wind projects. Additionally, we expect that solar development will accelerate with current low solar panel prices and the extension of Federal tax benefits for solar projects through 2016. Our primary focus is the construction of renewable energy infrastructure, including wind farms and solar farms. Regulatory mandates for electricity generation from alternative and renewable sources and the ARRA, which calls for expansion of domestic renewable energy sources through tax incentives, cash grants and loan guarantees, has provided our renewable energy operations with recent growth potential.

Work for Electrical Grid Upgrades – we believe that the nation’s electrical grid, which routinely encounters capacity and reliability issues, will be expanded, modernized and upgraded in the coming years. During the recent recession, demand for electric power has declined and has hidden many of the grid reliability issues which caused blackouts, brownouts and other grid failures in 2007 and early 2008. Also, renewable energy, which is often generated in remote areas, will require significant investment in new transmission and substation infrastructure in order to deliver this power to the population and to industrial centers with high electrical power demand. The ARRA has allocated $11 billion for modernization and expansion of the national electrical grid in order to develop a smart grid. With even a modest pickup in the economy, we believe that old grid reliability issues will reappear and that utilities across the country will respond by increasing their capital expenditures in this area. Additionally, we believe that cost and labor conditions are making it increasingly attractive for utilities to outsource their construction and maintenance activities.

Install to the Home – we believe the increased number of DIRECTV® subscribers and expansion of high definition video programming, special or proprietary programming, new technology set-top boxes and other in-home technology advances provide us with the continuing opportunity to provide installation, upgrade and maintenance services for new and existing customers. Our expertise in home installation also provides opportunities to offer installation services for new customers.

Heavy Industrial – we believe there will be increased demand for heavy industrial construction across a range of industries. The current low price and environmental advantage of clean burning natural gas should result in the conversion of coal fired power plants and the construction of new gas fired power plants. Additionally, a wide variety of industries may seek to expand, convert or construct new plants to take advantage of this economical and clean fuel source. We continue to expand our capabilities in heavy industrial construction in anticipation of this trend.

Our 2012 results could be adversely affected by the matters discussed in the “Cautionary Statement Regarding Forward-Looking Statements,” Item 1A. “Risk Factors” and Item 3. “Legal Proceedings” of this Annual Report on Form 10-K.

Comparisons of Fiscal Year Results

The following table reflects our consolidated results of operations in dollar and percentage of revenue terms for the periods indicated (dollar amounts in millions). Our consolidated results of operations are not necessarily comparable from period to period due to the impact of recent acquisitions. See Note 3 – Acquisition and Other Investments in the notes to consolidated financial statements.

 

     Year Ended December 31,  
     2011     2010     2009  

Revenue

   $ 3,009.0        100.0   $ 2,308.0        100.0   $ 1,623.5        100.0

Costs of revenue, excluding depreciation and amortization

     2,606.1        86.6        1,938.9        84.0        1,376.1        84.8   

Depreciation and amortization

     75.2        2.5        58.0        2.5        49.5        3.1   

General and administrative expenses

     148.4        4.9        126.7        5.5        96.9        6.0   

Interest expense, net

     34.4        1.1        29.1        1.3        24.7        1.5   

Other (income) expense, net

     (29.1     (0.9     1.3        0.0        (2.8     (0.3
  

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Income before provision for income taxes

   $ 174.0        5.8   $ 154.0        6.7   $ 79.1        4.9

Provision for income taxes

     (68.0     (2.3     (63.6     (2.8     (8.4     (0.5
  

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Net income

   $ 106.0        3.5   $ 90.4        3.9   $ 70.7        4.4

Net loss attributable to non-controlling interests

     (0.0     (0.0     (0.1     (0.0     —          —     
  

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Net income attributable to MasTec

   $ 106.0        3.5   $ 90.5        3.9   $ 70.7        4.4
  

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

The following discussion and analysis of our results of operations should be read in conjunction with our consolidated financial statements and notes thereto in Item 8 of this Form 10-K.

 

40


Table of Contents

Comparison of Years Ended December 31, 2011 and 2010

Revenue. Our revenue was $3.0 billion for year ended December 31, 2011, compared to $2.3 billion in 2010, representing an increase of $700.9 million, or 30.4%. Of this increase, $265.3 million, or approximately 38%, was attributable to businesses acquired during 2011. Revenues were favorably impacted by demand for our wireless, pipeline, install-to-the-home and energy transmission services. Key customers driving growth during 2011 included AT&T, DIRECTV® and Energy Transfer Company. Continuing investments in new infrastructure for wireless technology, in addition to expansion of the geographic areas in which we do project work, yielded approximately $237 million of higher revenues from wireless projects in 2011 as compared with 2010. Of this increase, approximately $27 million was from acquired businesses. Pipeline revenues increased approximately $212 million for the year ended December 31, 2011, driven by acquisition revenues of $83 million, as well as an increase of approximately $90 million from our pipeline projects in the various natural gas shale basins. Pipeline revenues were also favorably impacted by approximately $37 million of higher year-over-year revenues from a large pipeline project with El Paso Corporation. Install-to-the-home and energy transmission project activity was also strong in 2011, increasing by approximately $146 million and $138 million, respectively, including approximately $155 million of revenues from acquired businesses. Otherwise strong revenue growth was partially offset by approximately $118 million in lower levels of activity on renewable energy projects versus 2010 as a result of tightened access of our customers to project financing and delays resulting from changes to our customers’ capital spending projects.

Costs of Revenue. Our costs of revenue were $2.6 billion, or 86.6% of revenue, for the year ended December 31, 2011, compared to $1.9 billion, or 84.0% of revenue, for the corresponding period in 2010, a $667.2 million, or 34.4%, increase. The dollar increase is partially attributable to higher costs associated with increased revenues, as described above. As a percentage of revenue, costs of revenue increased 260 basis points. The basis point increase was driven by several factors, including an increase of approximately $27 million in certain commissions paid by DirectStar. Wages, including subcontractor costs increased as a percent of revenue by approximately 110 basis points, as a result of changes in our project mix as well as higher costs on certain of our pipeline, wireless, and renewable projects. For example, pipeline projects were negatively impacted by the flooding conditions we experienced on our Marcellus Shale basin pipeline projects in the second half of 2011. Severe flooding in the northeastern United States, caused by above average rainfall coupled with the effects of Hurricane Irene in August and Tropical Lee in September, hurt our pipeline projects in the Marcellus shale basin. In addition, we experienced higher labor costs on wireless projects as a result of certain growth-related project inefficiencies. Our renewable projects were negatively impacted by lower levels of utilization as a result of decreased revenues as well as from competitive pressure on pricing.

Our 2011 wage and employee costs also include the impact of a $6.4 million charge related to our multi-employer pension plans. In November 2011, we voluntarily withdrew from one of the multi-employer pension plans in which we participate. See Note 12 – Other Retirement Plans and Note 16 – Commitments and Contingencies in the notes to the consolidated financial statements for additional details. Fuel costs also increased by approximately 30 basis points as a percentage of revenue, driven by higher fuel prices and increased levels of fuel consumption to support growth in project work.

Depreciation and amortization. Depreciation and amortization was $75.2 million for the year ended December 31, 2011, as compared with $58.0 million for the same period in 2010, representing an increase of $17.2 million, or 29.7%. The increase was driven by $9.2 million of acquisition-related depreciation and amortization, as well as $8.1 million of higher organic business depreciation expense. The increase in organic business depreciation expense resulted from current year capital spending, primarily on pipeline and wireless projects, which increased depreciation expense by approximately $6 million, as well as from an increase of approximately $7 million in depreciation expense on certain equipment held under capital leases, which had previously been held under operating leases. The increase in depreciation expense from the lease reclassification was offset, in part, by a decrease in rent expense, which is recorded within costs of revenue. See Note 10 – Lease Obligations in the notes to the consolidated financial statements for additional details. Increased depreciation expense for the year ended December 31, 2011 was partially offset by a decrease of approximately $5 million in amortization expense from historical acquisitions.

General and administrative expenses. General and administrative expenses were $148.4 million, or 4.9% of revenue, for the year ended December 31, 2011 as compared with $126.7 million, or 5.5% of revenue, for the same period in 2010, representing an increase of $21.8 million, or 17.2%. The dollar increase resulted largely from approximately $14 million of higher labor costs associated with recently acquired businesses as well as from organic business growth. Acquisition-related transaction costs of approximately $1.6 million also contributed to higher general and administrative expenses. As a percentage of revenue, general and administrative expenses decreased approximately 60 basis points. This decrease was attributable to improved leveraging of overall administrative labor and other costs, which increased at a lower rate than the increase in revenue for the corresponding period.

Interest expense, net. Interest expense, net of interest income, was $34.4 million, or 1.1% of revenue, for the year ended December 31, 2011, as compared with $29.1 million, or 1.3% of revenue, for the same period in 2010, representing an increase of $5.3 million. This increase was largely attributable to $4.2 million of discount accretion associated with our New Convertible Notes and an increase in interest expense of approximately $1.2 million related to our credit facility. These increases were partially offset by a decrease in interest expense on equipment notes. In the fourth quarter of 2010, we refinanced $13.4 million of 7.05% equipment notes with a new equipment note bearing interest at approximately 3.53% per annum.

 

41


Table of Contents

Other (income) expense, net. Other income, net, was $29.1 million for the year ended December 31, 2011, as compared with other expense, net, of $1.3 million for the year ended December 31, 2010. The increase in other income, net, is largely attributable to a $29.0 million gain on remeasurement of our equity investment in EC Source, which was acquired in May 2011. Excluding this gain, other income, net, increased by $1.4 million.

Income taxes. Income taxes were $68.0 million for the year ended December 31, 2011, as compared with $63.6 million for the year ended December 31, 2010, representing an increase of $4.4 million. This increase is primarily due to higher taxable income, partially offset by the impact of a lower tax rate. Our effective tax rate was 39.1% for the year ended December 31, 2011 as compared with an effective tax rate of 41.3% for the year ended December 31, 2010. The lower current year tax rate is principally attributable to a higher deduction for production activities in 2011. Prior to 2011, these deductions were only available to us on a limited basis as we were benefiting from the use of net operating loss carryforwards.

Comparison of Years Ended December 31, 2010 and 2009

Revenue. Our revenue was approximately $2.3 billion for the year ended December 31, 2010, compared to $1.6 billion in 2009, representing an increase of approximately $685 million or 42.2%. Of the total increase, approximately $294.0 million resulted from acquisitions. The remaining increase of $390.5 million, or 24%, was attributable to organic growth, primarily from our wireless, pipeline, renewables and install to the home customers. Versus the prior year, wireless project revenues increased by over $200 million, pipeline revenues increased by over $90 million, and renewables and install-to-the-home project revenues each increased by approximately $80 million, respectively. Key customers driving growth in 2010 included AT&T, El Paso Corporation, DIRECTV®, Tenaska Energy, Edison Mission Energy and Talisman Energy. Our organic revenue growth was partially offset by the impact of economic and competitive pressures, which negatively impacted pricing and growth in certain components of our business. We actively monitor economic and industry trends and any related impact on our business, including certain wireline projects, which decreased by approximately $40 million versus the prior year.

Costs of revenue. Our costs of revenue were approximately $1.9 billion, or 84.0% of revenue for the year ended 2010, compared to $1.4 billion, or 84.8% of revenue for the year ended 2009, a $562.8 million increase, or 40.9%. The dollar increase was attributable to higher costs associated with increased revenues, as discussed above. As a percentage of revenue, costs of revenue decreased 80 basis points. This improvement was attributable to higher utilization of resources resulting from our revenue growth. Our margins have also been favorably impacted by business mix, as well as from productivity gains, such as deployment of resources across multiple reporting units, including certain of our renewable projects. As discussed above, certain components of our business have been negatively impacted by economic factors, which partially offset our margin improvements.

Depreciation and amortization. Depreciation and amortization was $58.0 million in 2010, compared to $49.5 million in 2009, representing an increase of $8.5 million or 17%. The increase was primarily driven by our prior year acquisition of Precision, which resulted in an incremental $11.1 million in depreciation and $1.5 million in amortization, partially offset by a decrease of $2.9 million in depreciation on past investments in information technology and a decrease of $1.4 million in amortization expense from historical acquisitions.

General and administrative expenses. General and administrative expenses were $126.7 million, or 5.5% of revenue in 2010, compared to $96.9 million, or 6.0% of revenue in 2009, representing an increase of $29.7 million, or 30.7%. The dollar increase resulted largely from increases in labor and other costs in support of the growth in our business, as discussed above. Labor costs comprised approximately $16 million of this increase. As a percentage of revenue, general and administrative expenses decreased 50 basis points. Our 2009 general and administrative expenses were partially offset by the receipt of a settlement award of approximately $2.0 million in connection with the settlement of a legacy litigation matter. Excluding this settlement, general and administrative expenses were 6.1% of revenue in 2009, resulting in a net 60 basis points improvement in general and administrative expenses from 2009 to 2010. This improvement was attributable to improved utilization of investments in labor and technology, which increased at a lower rate than the increase in revenue for the corresponding period.

Interest expense, net. Interest expense, net of interest income, was $29.1 million, or 1.3% of revenue in 2010, compared to $24.7 million, or 1.5% of revenue in 2009, representing an increase of $4.4 million. This increase was primarily attributable to $215 million of Original Convertible Notes issued in 2009, partially offset by a reduction in interest expense from the repayment of our $55 million 8% convertible note in June 2009 and the October 2010 refinancing of $13.4 million of a 7.05% equipment note with a new equipment note, bearing interest at 3.5267%. Because we have higher average debt balances in 2010, our interest expense increased versus the prior year.

Other expense (income), net. Other expense, net, was $1.3 million in 2010 compared to other income, net, of $2.8 million in 2009. The reduction in other income of $4.1 million as compared with 2009 was partially attributable to credit and other losses, net, of $0.8 million recognized during 2010 on our auction rate securities, versus the impact in 2009 of a $7.0 million settlement on litigation related to our auction rate securities, which was partially offset by $6.1 million of credit losses. Other expense was also impacted by a $0.9 million decrease in gains on sales of assets as compared with 2009. In addition, in 2010, we incurred $0.3 million in lease termination costs, $0.3 million of losses on equity method investments and $0.5 million of expense related to changes in the estimated fair value of acquisition-related contingent consideration. See Note 3 – Acquisitions and Other Investments in the notes to the consolidated financial statements.

 

 

42


Table of Contents

Income taxes. Income taxes were $63.6 million in 2010, compared with $8.4 million in 2009, representing an increase of $55.2 million. This increase was primarily due to a higher effective tax rate. Our 2009 rate was significantly lower because we released valuation allowances that were established against certain deferred tax assets in prior years, including net operating loss carryforwards. The release of these valuation allowances for the year ended 2009 reduced our total income tax expense, resulting in an effective tax rate of 10.6% as compared with an effective tax rate of 41.3% for year ended 2010.

Diluted Weighted Average Shares Outstanding

 

     For the Years Ended December 31,  
     2011      2010      2009  

Diluted weighted average shares outstanding (in thousands)

     86,718         90,913         81,763   
  

 

 

    

 

 

    

 

 

 

Our diluted share count decreased to 86.7 million shares in 2011 from 90.9 million shares in 2010. The exchange of 94% of our Original Convertible Notes for the New Convertible Notes that have an optional physical (share), cash or combination settlement feature in the first quarter of 2011 resulted in 10.4 million fewer shares in our diluted share count as compared with 2010. In addition, during the fourth quarter of 2011, our Board of Directors authorized a share repurchase program. We repurchased 4.6 million shares under this program, which reduced our 2011 diluted average share count by 0.6 million shares. These decreases were partially offset by the issuance of 5.1 million shares in connection with the EC Source business combination in May of 2011 and the issuance of 1.9 million shares in December 2010 in connection with a purchase agreement amendment for one of our historical acquisitions. In 2010, our diluted share count increased to 90.9 million shares from 81.8 million shares in 2009 primarily as a result of the 2009 issuances of $215 million of the Original Convertible Notes, of which 94% were exchanged for New Convertible Notes in 2011. See Note 3 – Acquisitions and Other Investments as well as Note 2 – Earnings Per Share in the notes to the consolidated financial statements contained for additional details.

Non-U.S. GAAP Financial Measures

As appropriate, we supplement the reporting of our financial information determined in accordance with U.S. GAAP with certain non-U.S. GAAP financial measures, including earnings before interest, taxes, depreciation and amortization (“EBITDA”); and, for 2011, we have presented adjusted net income; adjusted diluted net income per share; and “Adjusted EBITDA,” which exclude the $29.0 million non-cash gain on remeasurement of our equity investment in EC Source that we recorded in 2011, as well as a $6.4 million charge associated with our withdrawal from a multi-employer pension plan in the fourth quarter of 2011. See Note 3 – Acquisitions and Other Investments, Note 12 – Other Retirement Plans and Note 16 – Commitments and Contingencies in the notes to the consolidated financial statements for additional details. We believe these non-U.S. GAAP measures provide meaningful information in understanding our financial results and assessing our prospects for future performance. Because non-U.S. GAAP financial measures are not standardized, it may not be possible to compare these financial measures with other companies’ non-U.S. GAAP financial measures having the same or similar names. These adjusted financial measures should not be considered in isolation or as a substitute for reported net income and diluted net income per share. These non-U.S. GAAP financial measures reflect an additional way of viewing aspects of our operations that, when viewed with our U.S. GAAP results and the provided reconciliations to the corresponding U.S. GAAP financial measures, provide a more complete understanding of our business. We strongly encourage investors and shareholders to review our financial statements and publicly filed reports in their entirety and not rely on any single financial measure.

Adjusted Earnings Before Interest, Taxes, Depreciation and Amortization

EBITDA is a non-U.S. GAAP financial measure that reflects earnings excluding the impact of interest expense, provision for income taxes, depreciation and amortization. Adjusted EBITDA, which is a non-U.S. GAAP financial measure applicable to our 2011 results, is calculated as EBITDA excluding: (i) the $29.0 million non-cash gain on remeasurement of our equity investment in EC Source resulting from our acquisition of its remaining outstanding equity interests in May 2011; and (ii) the $6.4 million charge we recorded in connection with our withdrawal from a multi-employer pension plan. We use Adjusted EBITDA to evaluate our performance, both internally and versus our peers, because it excludes certain items that may not be indicative of our core operating results, as well as items that can vary widely across different industries or among companies within the same industry. Management also considers Adjusted EBITDA to be an indicator of our ability to generate cash, which can be used to measure our ability to service debt, fund capital expenditures and expand our business.

Interest expense can be dependent upon a company’s capital structure, debt levels and credit ratings. Accordingly, the impact of interest expense on earnings can vary significantly among companies. During the first quarter of 2011, our interest expense increased due to the inclusion of accretion expense associated with our New Convertible Notes, which contain an optional physical (share), cash or combination conversion feature. Issuers of convertible debt instruments that can be settled in cash or other assets on conversion are required to separately account for the liability and equity components of the instrument in a manner that reflects what the entity’s borrowing rate would have been on identical, nonconvertible debt as of the instrument’s issuance date. As a result, we separated the principal balance of the New Convertible Notes between the fair value of the debt component and the fair value of the common stock conversion feature. We discounted the values of the New Convertible Notes at an estimated rate of 6.73%. The resulting debt discount will be accreted to interest expense over the remaining terms of the New Convertible Notes using the effective interest method, which will increase interest expense above the New Convertible Notes’ 4.0% and 4.25% cash coupon interest rates.

 

43


Table of Contents

Tax positions of companies can vary because of differing abilities to take advantage of tax benefits and because of the tax policies of the jurisdictions in which they operate. As a result, effective tax rates and provisions for income taxes can vary considerably among companies and over time. For example, our effective tax rate for the year ended December 31, 2011 decreased to 39.1% from 41.3% in 2010. This decrease was attributable to a higher deduction for production activities in 2011. In 2009, our tax rate was 10.6%. The release of substantially all of our valuation allowances in 2009 significantly reduced our effective tax rate and resulting income tax expense. These valuation allowances had previously been established against certain deferred tax assets, including net operating losses.

The table below summarizes our effective tax rates for the periods indicated:

 

     For the Years Ended December 31,  
     2011     2010     2009  

Effective tax rate

     39.1     41.3     10.6

Depreciation and amortization can also affect comparability because companies utilize productive assets of different ages and use different methods of both acquiring and depreciating productive assets. These differences can result in considerable variability in the relative costs of productive assets and depreciation and amortization expense among companies.

EBITDA and Adjusted EBITDA should not be considered in isolation from, and are not intended to represent an alternative measure of, operating results or net income as determined in accordance with U.S. GAAP. The definitions of EBITDA and Adjusted EBITDA above are not the same as in our credit facility or in the indentures governing our notes; therefore, EBITDA and Adjusted EBITDA as presented in this discussion should not be used for purposes of determining our compliance with related covenants.

The following table reflects a reconciliation of Adjusted EBITDA, in dollar and percentage of revenue terms, for the periods indicated (dollar amounts in millions). The table below may contain slight summation differences due to rounding.

 

     For the Years Ended December 31,  
     2011     2010     2009  

Adjusted EBITDA Reconciliation:

              

Net income

   $ 106.0        3.5   $ 90.4         3.9   $ 70.7         4.4

Gain from remeasurement of equity interest in acquiree

     (29.0     (1.0 )%      —           —          —           —     

Multi-employer pension plan withdrawal charge

     6.4        0.2     —           —          —           —     

Interest expense, net

     34.4        1.1     29.1         1.3     24.7         1.5

Provision for income taxes

     68.0        2.3     63.6         2.8     8.4         0.5

Depreciation and amortization

     75.2        2.5     58.0         2.5     49.5         3.1
  

 

 

   

 

 

   

 

 

    

 

 

   

 

 

    

 

 

 

Adjusted EBITDA

   $ 261.1        8.7   $ 241.1         10.4   $ 153.4         9.4
  

 

 

   

 

 

   

 

 

    

 

 

   

 

 

    

 

 

 

Adjusted Net Income and Adjusted Diluted Net Income Per Share

Management believes adjusted net income and adjusted diluted net income per share are important indicators of our operations because they exclude items that may not be indicative of, or are unrelated to, our core operating results, and provide a baseline for analyzing trends in our underlying business. The following table presents adjusted net income and adjusted diluted net income per share for the stated period:

 

     Year Ended
December 31, 2011
 

Adjusted net income (in millions)

   $ 92.2   
  

 

 

 

Adjusted diluted net income per share

   $ 1.07   
  

 

 

 

 

44


Table of Contents

The tables below reconcile the non-U.S. GAAP financial measures, adjusted net income and adjusted diluted net income per share, with the most directly comparable U.S. GAAP financial measures, reported net income and reported diluted net income per share. The table below may contain slight summation differences due to rounding.

 

     Year Ended December 31, 2011  
     Net Income
Attributable to
MasTec

(in millions)
    Diluted Net
Income Attributable
to MasTec per
Diluted Share
 

Reported U.S. GAAP measure

   $ 106.0      $ $1.23   

Gain on remeasurement of equity interest in acquiree (a)

     (17.7     (0.20

Multi-employer pension plan withdrawal charge (b)

     3.9        0.05   
  

 

 

   

 

 

 

Adjusted non-U.S. GAAP measure

   $ 92.2      $ 1.07   
  

 

 

   

 

 

 

 

(a) Represents the after tax gain and corresponding diluted per share impact from the gain on remeasurement of our equity investment in EC Source, which was acquired in May 2011. The tax effect was calculated using the consolidated effective tax rate for the respective period. See Note 3 – Acquisitions and Other Investments in the notes to the consolidated financial statements for details.
(b) Represents the after tax charge and corresponding diluted per share impact related to our withdrawal from a multi-employer pension plan. We recorded a charge of $6.4 million within costs of revenue in the fourth quarter of 2011 related to this withdrawal. The tax effect was calculated using the consolidated effective tax rate for the respective period. See Note 12 – Other Retirement Plans and Note 16 – Commitments and Contingencies in the notes to the consolidated financial statements for details.

Financial Condition, Liquidity and Capital Resources

Our primary sources of liquidity are cash flows from continuing operations, availability under our credit facility and our cash balances. Our primary liquidity needs are for working capital, income taxes, capital expenditures, insurance collateral in the form of cash and letters of credit, earn-out obligations and debt service. We also evaluate opportunities for strategic acquisitions and/or investments from time to time that may require cash, and may consider opportunities to either repurchase outstanding debt or repurchase outstanding shares of our common stock in the future. See Item 5 for details of our share repurchase program, which was announced in November 2011.

Capital Expenditures. We estimate that we will spend approximately $65.0 million in 2012 on capital expenditures. In 2011, we spent approximately $72 million on capital expenditures, primarily to support project activity growth for pipeline and wireless activities, as well as in support of businesses acquired in 2011. We also invested in capital expenditures to support growth in our business, in particular on pipeline and wireless projects. The nature of our business is equipment intensive and actual capital expenditures can increase or decrease from estimates depending upon business activity levels. We will continue to evaluate lease versus buy decisions to meet our equipment needs and based on this evaluation, our capital expenditures may increase or decrease in the future. In January 2011, we modified the terms of certain of our equipment operating leases. The modifications led to a change in classification of the corresponding leases from operating to capital leases. As a result, $23.4 million of capital lease assets and corresponding capital lease obligations were recorded as of January 1, 2011. We also expect to continue to sell older equipment as we upgrade to new equipment.

Earn-out Payments. We have made certain acquisitions and have agreed to pay earn-out payments to certain of the sellers, generally based on the future performance of the acquired businesses. Certain of these earn-out payments may be made in either cash or, under certain circumstances, MasTec common stock, or a combination thereof, at our option. The estimated total value of future earn-out obligations recorded as liabilities as of December 31, 2011 is approximately $96.4 million, of which $46.4 million was added during the year ended December 31, 2011 for our 2011 acquisitions. Potential future earn-out obligations, for acquisitions beginning with the acquisition of Precision Pipeline LLC and Precision Transport Company, LLC (together, “Precision”), are measured at their estimated fair value as of the date of acquisition, with subsequent changes in fair value recorded in earnings as a component of other income or expense. During the years ended December 31, 2011, 2010 and 2009, we made cash payments of $44.7 million, $80.6 million and $20.6 million, respectively, related to earn-out obligations. Of the $80.6 million paid in 2010, $40 million related to a one time payment in connection with the Nsoro acquisition. In December 2010, we amended the Nsoro purchase agreement and paid the seller of Nsoro a one time payment of $40 million and issued 1.875 million shares of MasTec common stock, which were valued at $27 million. The amendment effectively reduced potential future earn-out payments in exchange for upfront consideration. See Note 3 – Acquisitions and Other Investments in the notes to the consolidated financial statements for additional details.

Income Taxes. Our cash tax payments increased to $27.8 million for the year ended December 31, 2011 from $5.7 million for the year ended December 31, 2010. In 2009, our cash tax payments were $2.1 million. Our cash tax payments have increased in 2011 as we utilized substantially all of our available net operating loss carryforwards in the fourth quarter of 2010, which reduced our cash tax payments during 2010 and 2009.

Working Capital. We need working capital to support seasonal variations in our business, primarily due to the impact of weather conditions on external construction and maintenance work and the spending patterns of our customers, both of which influence the timing of

 

45


Table of Contents

associated spending to support related customer demand. Our business is typically slower in the first quarter of each calendar year and, we generally experience seasonal working capital needs from approximately April through October to support growth in unbilled revenue and accounts receivable, and to a lesser extent, inventory. Timing of project close-outs can also contribute to increases or decreases in unbilled revenue. Our accounts receivable balances, including unbilled revenue, grew from $444 million in 2010 to $665 million in 2011, driven primarily by revenue growth. In addition, our inventory balances have grown from approximately $57 million as of December 31, 2010 to $89 million as of December 31, 2011, primarily to support growth from our wireless customers.

Our billing terms are generally net 30 days, and some of our contracts allow our customers to retain a portion (from 2% to 15%) of the contract amount until the job is completed. For certain customers, we maintain inventory to meet the material requirements of the contracts. Occasionally, certain of our customers pay us in advance for a portion of the materials we purchase for their projects, or allow us to pre-bill them for materials purchases up to specified amounts. Vendor terms are generally 30 days. Our agreements with subcontractors often contain a “pay-when-paid” provision, whereby our payments to subcontractors are made only after we are paid by our customers.

New Convertible Notes – Settlements. As of December 31, 2011, our common stock trading price exceeded the $15.76 and $15.48 conversion prices of our outstanding 4.0% and 4.25% senior convertible notes, respectively. Currently, we intend to settle the principal amounts of our New Convertible Notes upon any conversion thereof in cash. As of December 31, 2011, we had outstanding $202.3 million aggregate principal amount of our New Convertible Notes. Notwithstanding our present intention to settle conversions of our New Convertible Notes in cash, we cannot assure you that we will be able to do so due to restrictions under our Credit Facility. See the discussion of our Credit Facility below for additional details If we were required to settle conversions of our New Convertible Notes in accordance with our stated intent to settle principal amounts due in cash, and we were unable to do so with existing cash balances or through our Credit Facility, we could be required to obtain additional funding or settle such conversions by issuing shares of our common stock, which would be dilutive to existing shareholders. We cannot be certain that such funding would be available on terms acceptable to us, or at all.

Summary of Financial Condition, Liquidity and Capital Resources

General U.S. and global economic conditions have not had a significant impact on our overall financial position, results of operations or cash flows for the year ended December 31, 2011; however, severe weather conditions beginning in the third quarter of 2011 reduced our 2011 productivity and margins. See “Overview of Results” above for related discussion. Given the generally good credit quality of our customer base, we do not expect collections issues to materially impact our liquidity in the next twelve months. In addition, as a result of our current capital structure, including our credit facility, we do not anticipate that current overall market and economic conditions will materially impact our liquidity. We anticipate that funds generated from operations, borrowings under our credit facility and our cash balances will be sufficient to meet our working capital requirements, anticipated capital expenditures, insurance collateral requirements, earn-out obligations, multi-employer pension plan withdrawal obligations, letters of credit and debt service obligations for at least the next twelve months.

Sources and Uses of Cash

As of December 31, 2011, we had $242.3 million in working capital, defined as current assets less current liabilities, compared to $235.1 million as of December 31, 2010. Cash and cash equivalents of $20.3 million as of December 31, 2011 decreased by $157.3 million from cash and cash equivalents of $177.6 million as of December 31, 2010. Cash and cash equivalents as of December 31, 2010 included approximately $18.0 million of restricted cash related to collateral for certain letters of credit, which was invested in certificates of deposit with maturities of 90 days.

Sources and uses of cash are summarized below (in millions):

 

     For the Years Ended December 31,  
     2011     2010     2009  

Net cash provided by operating activities

   $ 5.8      $ 218.0      $ 124.1   

Net cash used in investing activities

   $ (146.6   $ (104.3   $ (176.0

Net cash (used in) provided by financing activities

   $ (16.8   $ (24.7   $ 93.3   

Operating activities. Cash flow from operations is primarily influenced by demand for our services, operating margins and the type of services we provide, but can also be influenced by working capital needs such as the timing of billings and collections of receivables and the settlement of payables and other obligations. A portion of working capital assets is typically converted to cash in the first quarter. Conversely, working capital needs generally increase from April through October due to the seasonality of our business. Net cash provided by operating activities of $5.8 million for the year ended December 31, 2011 decreased by $212.2 million from $218.0 million of cash provided by operating activities in 2010. The decrease in cash provided by operating activities was principally driven by changes in accounts receivable and unbilled revenue as well as billings in excess of costs and earnings. Accounts receivable balances grew to $665 million in 2011 from $444 million in 2010, as discussed further below. Additionally, billings in excess of costs and earnings decreased by $26.3 million for the year ended December 31, 2011, as compared with an increase of $86.2 million in 2010.

 

46


Table of Contents

Growth in accounts receivable and unbilled revenue was driven by several factors, certain of which resulted in a higher days sales outstanding versus the prior year. Among the factors contributing to growth in accounts receivable and unbilled revenue are: revenue growth, timing of project close-outs and related billings, contractual billing terms and pace of collections. Changes in our project and customer mix, in addition to increased lead times on certain project billings for wireless projects, resulted in an increase in days sales outstanding. We are actively working to reduce our backlog of wireless project billings and do not anticipate difficulties in collecting the related receivables. Inventory balances have also increased to support growth in our wireless business. Accounts payable and accrued expenses increased as a result of higher payroll and project expenses as well as timing of related disbursements.

Investing activities. Net cash used in investing activities increased by $42.3 million to $146.6 million for the year ended December 31, 2011 from $104.3 million in 2010. The increase was primarily driven by an increase in capital expenditures. The increase in capital expenditures of $41.3 million included capital spending associated with increased activity levels, primarily from pipeline and wireless projects, as well as from acquisition-related capital expenditures for businesses acquired in 2011. Cash payments for acquisitions and earn-out obligations of $85.0 million in 2011 was slightly lower than in 2010, which totaled $86.8 million, including $10.9 million of payments for equity investments. As discussed in Note 3 – Acquisitions and Other Investments in the notes to the consolidated financial statements, we acquired certain businesses in 2011. Purchase price consideration for these acquisitions included approximately $85.4 million in cash, net of cash acquired, including the assumption of $26.0 million of debt, $12.1 million of which was repaid immediately.

Financing Activities. Cash used in financing activities for the year ended December 31, 2011 was $16.8 million, as compared to $24.7 million of cash used in financing activities for the year ended December 31, 2010. During 2011, we paid $75.0 million for common stock repurchases. We also paid approximately $7 million for financing costs related to our credit facility amendment and debt exchange transactions, both of which took place in 2011. These payments were offset by $60.0 million of net proceeds from our credit facility, and an increase of approximately $17 million in proceeds from share based awards and related excess tax benefits, as well as a decrease of approximately $13 million in repayments of other borrowings.

During the fourth quarter of 2011, our Board of Directors authorized a share repurchase plan, under which we repurchased 4.6 million shares of treasury stock for $75.0 million. These treasury stock purchases were financed primarily using proceeds from our Credit Facility. See Note 13 – Common Stock Activity in the notes to the consolidated financial statements for details. In addition, during 2011, approximately 1.1 million stock options were exercised for cash proceeds of approximately $12 million, and we recorded approximately $8 million of excess tax benefits relating to stock option exercises and vesting of restricted share awards.

Credit Facility

In August 2011, we entered into an amendment to our previous credit facility which amended and restated our previous credit facility in its entirety, expanded maximum available borrowing capacity from $260 million to $600 million and extended the maturity date from May 2013 until August 2016.

The amended credit facility (the “Credit Facility”) provides for a $600 million senior secured revolving credit facility maturing on August 22, 2016. Up to $350 million of the Credit Facility is available for the issuance of letters of credit. Subject to certain terms in the Credit Facility, we have the option to increase our revolving commitments and/or establish term loans of up to $200 million in total. Borrowings under the Credit Facility will be used to refinance existing indebtedness and for working capital, capital expenditures and other corporate purposes, including the repurchase or prepayment of indebtedness; however, the Credit Facility restricts the repurchase or prepayment of certain unsecured indebtedness, including our senior notes due 2017 and senior convertible notes due 2014, unless we have at least $50 million of remaining liquidity (as defined in the Credit Facility) after any such repurchase or prepayment.

The Credit Facility requires that we maintain a consolidated leverage ratio (as defined in the Credit Facility) at or below 3.50 to 1.00 and a consolidated interest coverage ratio (as defined in the Credit Facility) at or above 3.00 to 1.00. Subject to customary exceptions, the Credit Facility also limits our ability to engage in certain activities, including acquisitions, mergers and consolidations, debt incurrence, investments, capital expenditures, asset sales, debt prepayments, lien incurrence and the making of distributions on or repurchases of capital stock.

Following the date on which we deliver our financial information to the lenders for the quarter ending March 31, 2012 (the “Interest Adjustment Date”), amounts borrowed under the Credit Facility will bear interest, at our option, at a rate equal to either (a) the eurocurrency rate (as defined in the Credit Facility), plus a margin of 1.50% to 2.50%, as determined based on our consolidated leverage ratio (as defined in the Credit Facility) as of the most recent fiscal quarter, or (b) the base rate, (which is equal to the highest of (i) the federal funds rate (as defined in the Credit Facility) plus 0.5%, (ii) Bank of America’s prime rate and (iii) the eurocurrency rate plus 1.00%, plus a margin of 0.50% to 1.50%, as determined based on our consolidated leverage ratio as of the most recent fiscal quarter. Prior to the Interest Adjustment Date, the margin for eurocurrency rate loans will be fixed at 2.00%, and the margin for base rate loans will be fixed at 1.00%. Following the Interest Adjustment Date, financial standby letters of credit and commercial letters of credit issued under the Credit Facility will be subject to a letter of credit fee of 1.50% to 2.50% and performance standby letters of credit will be subject to a letter of credit fee of 0.75% to 1.25%, based on our consolidated leverage ratio as of the then most recent fiscal quarter. Prior to the Interest Adjustment Date, this

 

47


Table of Contents

fee will be fixed at 2.00% and 1.00% respectively. We must also pay a commitment fee to the lenders on any unused availability under the Credit Facility which fee, following the Interest Adjustment Date, will be equal to 0.25% to 0.45%, based on the Company’s consolidated leverage ratio as of the then most recent fiscal quarter. Prior to the Interest Adjustment Date, this fee will be fixed at 0.35%.

As of December 31, 2011, we had outstanding revolving loans of $60.0 million and approximately $90.0 million of letters of credit issued under our Credit Facility. The remaining $450.0 million of Credit Facility borrowing capacity was available for revolving loans or up to $260.0 million of new letters of credit. Outstanding letters of credit mature at various dates and most have automatic renewal provisions, subject to prior notice of cancellation. As of December 31, 2011, interest on outstanding revolving loans accrued at a rate of 2.94% per annum and interest on outstanding letters of credit accrued at either 1% or 2% per annum, based on the type of letter of credit issued, as defined above. The unused facility fee as of December 31, 2011 was 0.35%.

The Credit Facility is guaranteed by most of our U.S. subsidiaries, and it is collateralized by a first priority security interest in substantially all of our assets and the assets of our wholly-owned subsidiaries and a pledge of the outstanding equity interests in certain of our operating subsidiaries. The Credit Facility also provides for customary events of default and carries cross-default provisions with our other significant debt instruments, including our indemnity agreement with our surety provider, as well as customary remedies upon an event of default (as defined in the Credit Facility), including the acceleration of repayment of outstanding amounts and other remedies with respect to the collateral securing the Credit Facility obligations.

Based upon current availability under our Credit Facility, our liquidity and our anticipated cash flow, we believe we will be in compliance with the Credit Facility’s terms and conditions for the next twelve months. We are dependent upon borrowings and letters of credit under the Credit Facility to fund our operations. Should we be unable to comply with the terms and conditions of the Credit Facility, we would be required to obtain modifications to the Credit Facility or obtain an alternative source of financing to continue to operate, neither of which may be available to us on commercially reasonable terms, or at all.

Cash Overdrafts

On a daily basis, available funds are swept from our depository accounts into a concentration account and are used to repay debt under our Credit Facility. Cash overdrafts principally represent the balance of outstanding checks that have not yet cleared through the banking system. Other cash balances maintained by certain operating subsidiaries, which are not swept into our concentration account, as well as deposits made subsequent to the daily cash sweep, are classified as cash. We generally do not fund our disbursement accounts for checks we have written until the checks are presented to the bank for payment. Cash overdrafts are classified within accounts payable. There are no compensating balance requirements associated with our depository accounts, and, with the exception of cash balances maintained by certain operating subsidiaries that are not available for sweep, there are no other restrictions on the transfer of cash associated with our depository accounts. As of December 31, 2011, cash overdrafts, which are classified within financing activities in the consolidated statements of cash flows, totaled $14.9 million.

Senior Convertible Notes

New Senior Convertible Notes. During the first quarter of 2011, we exchanged $105.3 million of our 4.0% senior convertible notes due 2014 (the Original 4.0% Notes”) and $97.0 million of our 4.25% senior convertible notes due 2014, (the “Original 4.25% Notes” and, collectively with the Original 4.0% Notes, the “Original Notes”), both of which were issued in 2009, for identical principal amounts of new 4.0% and 4.25% senior convertible notes (the “New 4.0% Notes” and “New 4.25% Notes,” respectively, and collectively, the “New Convertible Notes”) for an exchange fee of approximately 50 basis points, or approximately $1 million. In connection with the exchange, transaction costs of approximately $0.7 million have been recognized within general and administrative expenses, of which $0.5 million was recognized during the quarter ended December 31, 2010. The terms of the New Convertible Notes are substantially identical to those of the Original Notes, except that the New Convertible Notes have an optional physical (share), cash or combination settlement feature and contain certain conditional conversion features. During 2011, an immaterial principal amount of Original Notes was converted into shares of our common stock. As of December 31, 2011, $12.7 million principal amount of the Original Notes remains outstanding.

The New Convertible Notes are convertible at any time during the three months immediately preceding their respective maturity dates; prior to such time, however, the New Convertible Notes are convertible only if one of the following three conditions is satisfied:

 

   

if the last reported sale price of our common stock is greater than or equal to 130% of the applicable conversion price of the New Convertible Notes during at least 20 of the last 30 consecutive trading days ending on and including the last trading day of a calendar quarter, then the applicable New Convertible Notes may be converted during the immediately following calendar quarter (and only during such calendar quarter);

 

48


Table of Contents
   

if after any five consecutive trading-day period in which the trading price per $1,000 principal amount of New Convertible Notes for each trading day during such period was less than 98% of the product of the last reported sale price of our common stock and the applicable conversion rate, then the applicable New Convertible Notes may be converted during the immediately following five business day period; or

 

   

if we effect certain distributions to our shareholders or we are a party to a consolidation, merger, binding share exchange, or a sale, transfer, lease or other conveyance of all or substantially all of our assets, pursuant to which our common stock would be converted into or exchanged for, or would constitute solely the right to receive, cash, securities or other assets, or in the case of certain other fundamental changes, then the New Convertible Notes may be converted during the period that is 45 trading days prior to the ex-dividend date or the initial anticipated effective date of the transaction, as applicable.

Because the New Convertible Notes have an optional cash settlement feature, and we intend to settle the principal amount of any conversions thereof in cash, the conversion shares underlying the principal amount of the New Convertible Notes, totaling approximately 13.0 million shares, are not included in our diluted share count. If, however, the average stock price per share exceeds the $15.76 conversion price for the New 4.0% Notes or the $15.48 conversion price for the New 4.25% Notes, then the resulting amount, in shares, of any premium will be included in our diluted share count (“premium shares”). Our average stock price exceeded the conversion prices of the New Convertible Notes for the year ended December 31, 2011. The total value of the premium over the principal amount for the New Convertible Notes as of December 31, 2011 was approximately $42.3 million. This resulted in the inclusion of 2.2 million weighted average premium shares in our diluted share count for the year ended December 31, 2011. For the year ended December 31, 2010, 13.0 million shares were included in our diluted share count for the corresponding principal amounts of Original Notes. The reduction in our diluted share count for the year ended December 31, 2011 was partially offset by a reduction of $4.7 million in the after-tax interest addback associated with the Original Notes under the “if-converted” method of accounting, as well as the inclusion of $4.2 million of after-tax accretion expense associated with the New Convertible Notes. See Note 2 – Earnings Per Share and Note 9 – Debt in the notes to the consolidated financial statements for additional details. The number of premium shares included in our diluted share count will vary with fluctuations in our share price. Higher actual share prices result in a greater number of premium shares. Because the number of shares required to be included in our diluted share count will vary with changes in our actual share price, we cannot predict the dilutive impact of any such premium shares in future periods.

Notwithstanding our present intention to settle conversions of our New Convertible Notes in cash, we cannot assure you that we will be able to do so due to restrictions under our Credit Facility, which restricts the repurchase or prepayment of certain unsecured indebtedness, including the Company’s senior notes due 2017 and senior convertible notes due 2014, unless the Company has at least $50 million of remaining liquidity (as defined in the Credit Facility) after any such repurchase or prepayment.

If we were required to settle conversions of our New Convertible Notes in accordance with our stated intent to settle principal amounts due in cash, and we were unable to do so with existing cash balances or through our Credit Facility, we could be required to obtain additional funding or settle such conversions in shares of our common stock, which would be dilutive to our existing shareholders. We cannot be certain that such funding would be available on terms acceptable to us, or at all.

Original Senior Convertible Notes. In November 2009, we issued $100 million of Original 4.25% Notes due December 15, 2014 in a private placement. Of this amount, $97.0 million was canceled and exchanged in the first quarter of 2011 for a like principal amount of New 4.25% Notes in connection with our debt exchange as discussed above. The Original 4.25% Notes bear interest at a rate of 4.25% per year, payable semi-annually in arrears, on June 15 and December 15 of each year. On or prior to December 12, 2014, holders may convert their Original 4.25% Notes into shares of our common stock at an initial conversion rate of 64.6162 shares of our common stock per $1,000 principal amount of Original 4.25% Notes, which represents an initial conversion price of approximately $15.48 per share, subject to customary anti-dilution adjustment terms for these types of notes. Approximately $3.7 million in financing costs were incurred in connection with the issuance of the Original 4.25% Notes. These deferred financing costs are included in other assets in the consolidated balance sheet and are being amortized over the term of the Original 4.25% Notes.

In June 2009, we issued $115 million of Original 4.0% Notes due June 15, 2014 in a registered offering. Of this amount, $105.3 million was canceled and exchanged in the first quarter of 2011 for a like principal amount of New 4.0% Notes in connection with our debt exchange as discussed above. The Original 4.0% Notes bear interest at a rate of 4.0% per year, payable semi-annually in arrears, on June 15 and December 15 of each year. On or prior to June 13, 2014, holders may convert their Original 4.0% Notes into shares of our common stock at an initial conversion rate of 63.4417 shares of our common stock per $1,000 principal amount of Original 4.0% Notes, which represents an initial conversion price of approximately $15.76 per share, subject to customary anti-dilution adjustment terms for these types of notes. Approximately $5.4 million in financing costs were incurred in connection with the issuance of the Original 4.0% Notes, which are included in other assets in the consolidated balance sheet and are being amortized over the term of the notes.

 

49


Table of Contents

The 4.25% and 4.0% senior convertible notes are guaranteed by substantially all of our operating subsidiaries. There are no financial covenants on these notes, however, there are certain nonfinancial provisions and covenants associated with these notes.

Senior Notes

We have $150 million of outstanding 7.625% senior notes due February 2017, with interest due semi-annually. The notes contain default (including cross-default) provisions and covenants restricting many of the same transactions as under our Credit Facility. The indenture that governs our 7.625% senior notes allows us to incur additional indebtedness to the extent that our fixed charge coverage ratio, as therein defined, is at least 2:1. The fixed charge coverage ratio is calculated as consolidated EBITDA for the most recent four fiscal quarters for which internal financial statements are available, divided by fixed charges for such four quarter period, as such terms are defined in the indenture. If the fixed charge coverage ratio is less than 2:1, we are still permitted to incur the following additional indebtedness, among others: credit facilities under a defined threshold, renewals to existing debt permitted under the indenture, capital lease obligations up to 5% of our consolidated net assets, plus an additional $50 million of indebtedness at any time the senior notes remain outstanding. The senior notes are guaranteed by substantially all of our operating subsidiaries.

Acquisition Debt

Equipment Term Loan. In connection with the acquisition of Pumpco, we entered into an equipment term loan in the aggregate amount of $22.5 million at 7.05% interest, payable in 60 monthly installments, maturing in 2013. In October 2010, we repaid the $13.4 million outstanding principal balance of the 7.05% equipment term loan with the proceeds of a new loan in the amount of $13.5 million, bearing interest at 3.5267%. The 3.5267% equipment term loan is payable in 36 monthly installments, maturing in 2013 and is secured by most of Pumpco’s existing equipment and guaranteed by MasTec. As of December 31, 2011, $8.3 million was outstanding on this equipment term loan.

Other Acquisition Related Debt. During the second quarter of 2011, we assumed approximately $26.0 million of debt and capital lease obligations in connection with certain acquisitions, of which $12.1 million was repaid immediately. As of December 31, 2011, approximately $10.1 million of related debt and capital lease obligations remains outstanding. Certain equipment debt related to these acquisitions is secured by the financed equipment. In addition, we assumed approximately $34 million in notes payable for equipment and capital lease obligations in connection with the acquisition of Precision in November 2009, and, in connection with the acquisition of Wanzek Construction, Inc. (“Wanzek”) in December 2008, we assumed approximately $15 million of its debt. As of December 31, 2011, $14.8 million remains outstanding on the Precision and Wanzek acquisition related debt described above.

Except for one note with an immaterial principal balance as of December 31, 2011, there are no financial covenants associated with the acquisition debt described above.

Debt Guarantees and Covenants

The Senior Notes, New Notes and Original Notes are fully and unconditionally guaranteed on an unsecured, unsubordinated, joint and several basis by our existing and future 100%-owned direct and indirect domestic subsidiaries that are guarantors of our Credit Facility or other outstanding indebtedness (the “Guarantors”). See supplemental financial information in Note 20 – Supplemental Guarantor Financial Information.

We were in compliance with all provisions and covenants pertaining to our outstanding debt instruments as of December 31, 2011.

Auction Rate Securities

Our securities available for sale consist of auction-rate securities, which represent interests in pools of student loans guaranteed by the U.S. government under the Federal Family Education Loan Program and a structured finance security. As of December 31, 2011, we held $17.9 million in par value of auction rate securities, with an estimated fair value and carrying value of $13.6 million. Cumulative unrealized losses totaled $1.0 million as of December 31, 2011, which are recorded in other comprehensive income, net of applicable income taxes.

Structured Finance Auction Rate Securities. As discussed in Note 6 – Securities Available for Sale in the notes to the consolidated financial statements, following the sale of two of our three structured finance auction rate securities in the fourth quarter of 2010, we determined that we no longer met the criteria for intent to hold with respect to our remaining structured finance security. Accordingly, subsequent declines in this security’s cost basis have been recognized in earnings, whereas increases will be recorded in other comprehensive income, net of applicable income taxes. For the year ended December 31, 2011, we recognized $0.6 million of other-than-temporary impairment losses in earnings associated with this security. As of December 31, 2011, this security’s par value and cost basis were $5.0 million and $1.7 million, respectively.

 

50


Table of Contents

Student Loan Auction Rate Securities. As of December 31, 2011, our student loan auction rate securities have a par value and cost basis of $12.9 million. As discussed in Note 6 – Securities Available for Sale in the notes to the consolidated financial statements, the issuer of one of our student loan auction rate securities redeemed its security at the security’s par value of $4.6 million during the second quarter of 2011. In connection with the redemption, $0.5 million of cumulative unrealized losses and its corresponding tax impact were eliminated from other comprehensive income. We continue to have intent to hold, and more likely than not, will not be required to sell our remaining student loan auction rate securities until maturity or until their par value can be recovered. Cumulative gross unrealized losses on these securities, which are included as a component of other comprehensive income, total $1.0 million, or $0.6 million, net of applicable income taxes, as of December 31, 2011.

Contractual Payment Obligations

The following table sets forth our contractual payment obligations as of December 31, 2011 during the periods indicated below (in millions):

 

Contractual Obligations

   Total      Less than
1 Year
     1 - 3
Years
     3 - 5
Years
     More than
5 Years and
Thereafter
 

Credit facility (1)

   $ 60.0       $ —         $ —         $ 60.0       $ —     

Senior notes

     150.0         —           —           —           150.0   

Senior convertible notes (2)

     215.0         —           215.0         —           —     

Notes payable for equipment

     43.5         19.9         21.1         2.5         —     

Earn-out obligations (3)

     21.8         21.8         —           —           —     

Capital leases

     40.6         14.3         24.7         1.6         —     

Operating leases

     117.4         39.7         53.9         19.6         4.2   

Obligations under multi-employer pension plan (4)

     6.4         —           —           —           6.4   

Interest (5)

     104.5         24.5         43.3         35.0         1.7   
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Total

   $ 759.2       $ 120.2       $ 358.0       $ 118.7       $ 162.3   
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

 

(1) Represents balance outstanding on our Credit Facility as of December 31, 2011, which matures in August 2016.
(2) Amount is comprised of $105.3 million of New 4.0% Notes, $9.7 million of Original 4.0% Notes, $97.0 million of New 4.25% Notes and $3.0 million of Original 4.25% Notes due in 2014. See Note 9Debt in the notes to the consolidated financial statements and “Senior Convertible Notes” above. The $202.3 million principal amount pertaining to our New Convertible Notes is composed of $188.1 million in carrying value and $14.2 million of unamortized debt discount and investor fees as of December 31, 2011.
(3) Under certain acquisition agreements, we have agreed to pay the sellers earn-outs based on the performance of the businesses acquired. Certain of these earn-out payments may be made in either cash or, under certain circumstances, MasTec common stock, or a combination thereof, at our option. Due to the contingent nature of these earn-out payments, we have only included earn-out obligations that we assume will be paid in cash, are quantifiable and have been earned as of December 31, 2011.
(4) Represents voluntary withdrawal liability recorded as of December 31, 2011 and excludes normal contributions required under our collective bargaining agreements. See Note 12 – Other Retirement Plans and Note 16 – Commitments and Contingencies in the notes to the consolidated financial statements.
(5) Interest represents interest payments due on all debt and capital lease obligations. All of our debt instruments, with the exception of our Credit Facility, which had $60.0 million outstanding as of December 31, 2011, are fixed rate interest obligations.

Off-balance sheet arrangements

As is common in our industry, we have entered into certain off-balance sheet arrangements in the ordinary course of business. Our significant off-balance sheet transactions include liabilities associated with non-cancelable operating leases, letter of credit obligations, surety and performance and payment bonds entered into in the normal course of business, self-insurance liabilities, liabilities associated with multi-employer pension plans and liabilities associated with certain indemnification and guarantee arrangements. We do not have any material off-balance sheet financing arrangements with variable interest entities.

Leases. In the ordinary course of business, we enter into non-cancelable operating leases for certain of our facility, vehicle and equipment needs, including related party leases. These leases allow us to conserve cash and provide flexibility in that we pay a monthly rental fee for use of the related facilities, vehicles and equipment rather than purchasing them. The terms of these agreements vary from lease to lease, including some with renewal options and escalation clauses. We may decide to cancel or terminate a lease before the end of its term, in which case we are typically liable for the remaining lease payments under the term of the lease. Rent expense related to operating leases, including short-term rentals, was approximately $173.1 million for the year ended December 31, 2011.

 

51


Table of Contents

Letters of Credit. In the ordinary course of business, we are required to post letters of credit, primarily for our insurance carriers and surety bond providers, and in support of performance under certain contracts. Such letters of credit are generally issued by a bank or similar financial institution. Letters of credit are also posted. The letter of credit commits the issuer to pay specified amounts to the holder of the letter of credit if the holder claims that we have failed to perform specified actions. If this were to occur, we would be required to reimburse the issuer of the letter of credit, which depending upon the circumstances, could result in a charge to earnings. As of December 31, 2011, we had $90.0 million of standby letters of credit issued under our Credit Facility, of which $51.4 million pertained to certain of our insurance carriers. We are not aware of any material claims relating to outstanding letters of credit as of December 31, 2011 and do not believe it is likely that any material claims will be made under any of our outstanding letters of credit in the foreseeable future. We may be required to post additional letters of credit or other collateral in favor of our insurance carriers, surety bond providers or customers in the future. Posting letters of credit reduces our borrowing availability under our Credit Facility.

Performance and Payment Bonds. In the ordinary course of business, we are required by certain customers to provide performance and payment bonds for some of our contractual commitments related to projects in process. These bonds provide a guarantee to the customer that we will perform under the terms of a contract and that we will pay subcontractors and vendors. If we fail to perform under a contract or to pay subcontractors and vendors, the customer may demand that the surety make payments or provide services under the bond. We must reimburse the surety for any expenses or outlays it incurs. If our business continues to grow, our bonding requirements may increase in the future. If we are unable to successfully renew or obtain sufficient bonding capacity in the future, it could limit our ability to bid on certain contracts or perform work for certain customers. As of December 31, 2011, the estimated cost to complete projects secured by our $905.7 million in performance and payment bonds was $330.0 million. We believe it is unlikely that we will have to fund significant claims under performance and payment bonds in the foreseeable future.

Included in our outstanding performance and payment bonds as of December 31, 2010 was approximately $3.0 million relating to the projects and assets of the state Department of Transportation business sold in 2007. In connection with the sale of these assets, we remained contingently liable for certain obligations, including liabilities associated with claims on these performance and payment bonds. The buyer of the Department of Transportation related projects and assets filed for bankruptcy protection in October 2009, which increased the likelihood that we would be required to assume certain obligations associated with these projects. As of December 31, 2011, we have completed the work associated with these projects, and we do not believe that we have any further obligations thereunder.

Self-Insurance. We maintain insurance policies subject to per claim deductibles of $1 million for our workers’ compensation policy, $2 million for our general liability policy and $2 million for our automobile liability policy. We have excess umbrella coverage up to $100 million per claim and in the aggregate. Liabilities under these insurance programs are accrued based upon our estimate of the ultimate liability for claims reported and an estimate of claims incurred but not reported, with assistance from third-party actuaries. These insurance liabilities are difficult to assess and estimate due to unknown factors, including the severity of an injury, the determination of our liability in proportion to other parties and the number of incidents not reported. Accruals are based upon known facts and historical trends and we believe such accruals to be adequate. As of December 31, 2011, our liability for unpaid claims and associated expenses, including incurred but not reported losses related to our workers compensation, general liability and automobile liability insurance policies, was $39.1 million, of which $22.3 million was reflected within non-current other liabilities.

We also maintain an insurance policy with respect to employee group health claims, which is subject to annual per employee maximum losses of $0.4 million. Our liability for employee group claims as of December 31, 2011, which is based on statistical analysis of historical claims experience and specific knowledge of actual losses that have occurred, was $1.4 million.

We are required to post letters of credit and provide cash collateral to certain of our insurance carriers and to provide surety bonds in certain states in which we are self-insured. As of December 31, 2011, these letters of credit amounted to $51.4 million. In addition, cash collateral deposited with insurance carriers, which is included in other long term assets in the consolidated balance sheet, amounted to $2.0 million as of December 31, 2011. Outstanding surety bonds related to self-insurance programs amounted to $7.1 million as of December 31, 2011.

Employment Agreements. We have employment agreements with certain executives and other employees, which provide for compensation and certain other benefits and for severance payments under certain circumstances. Certain employment agreements also contain clauses that become effective upon a change of control of the Company. Upon the occurrence of any of the defined events in the various employment agreements, we will pay certain amounts to the relevant employees, which vary with the level of the employees’ respective responsibility.

Collective Bargaining Agreements and Multi-Employer Pension Plans. Certain of MasTec’s subsidiaries are party to various collective bargaining agreements with unions representing certain of their employees. The agreements require the subsidiaries party to the agreements to pay specified wages, provide certain benefits to their union employees and contribute certain amounts to multi-employer pension plans and employee benefit trusts. The multi-employer pension plan contribution rates are determined annually and assessed on a

 

52


Table of Contents

“pay-as-you-go” basis based on union employee payrolls. The required amount of future contributions cannot be determined for future periods because the number of union employees employed at any given time, and the plans in which they may participate, vary depending upon the location and number of ongoing projects and the need for union resources in connection with those projects. The collective bargaining agreements expire at various times and have typically been renegotiated and renewed on terms similar to the ones contained in the expiring agreements.

The Employee Retirement Income Security Act of 1974, as amended by the Multi-Employer Pension Plan Amendments Act of 1980 (“ERISA”), subjects employers to substantial liabilities in the event of the employer’s complete or partial withdrawal from, or upon termination of, such plans. Under current law regarding employers who are contributors to multi-employer defined benefit plans, a plan’s termination, an employer’s voluntary withdrawal from, or the mass withdrawal of all contributing employers from, an underfunded multi-employer defined benefit plan requires participating employers to make payments to the plan for their proportionate share of the multi-employer plan’s unfunded vested liabilities. Furthermore, the Pension Protection Act of 2006 added new funding rules generally applicable to plan years beginning after 2007 for multi-employer plans that are classified as “endangered,” “seriously endangered,” or “critical” status. If plans in which we participate are in critical status, benefit reductions may apply and/or we could be required to make additional contributions if the plans are determined to be underfunded.

Based upon the information available to us from plan administrators as of December 31, 2011, several of the multi-employer pension plans in which we participate are underfunded. The Pension Protection Act requires that underfunded pension plans improve their funding ratios within prescribed intervals based on the level of their underfunding. In addition, if a multi-employer defined benefit plan fails to satisfy certain minimum funding requirements, the Internal Revenue Service may impose a nondeductible excise tax of 5% on the amount of the accumulated funding deficiency for those employers contributing to the fund. We have been notified that certain plans to which our subsidiaries contribute are in “critical” status and require additional contributions in the form of a surcharge on future benefit contributions required for future work performed by union employees covered by these plans. As a result, we expect our required contributions to these plans to increase in the future. The amount of additional funds we may be obligated to contribute in the future cannot be estimated, as such amounts will be based on future levels of work that require the specific use of those union employees covered by these plans.

On November 15, 2011, we, along with other members of the Pipe Line Contractors Association (“PLCA”), voluntarily withdrew from the Central States Southeast and Southwest Areas Pension Fund (“Central States”), a defined benefit multi-employer pension plan. In connection with this withdrawal, we recorded a $6.4 million withdrawal liability based on the date of withdrawal. We withdrew from the Central States Plan in order to mitigate our liability in connection with the plan, which is in critical status, however, the plan has asserted that the PLCA members did not effectively withdraw on November 15, 2011. Although, we believe that we legally and effectively withdrew from the plan on November 15, 2011, if Central States were to prevail in its assertion that we in fact withdrew after that date, then the amount of our withdrawal liability would increase. In addition, if this plan were to undergo a mass withdrawal, as defined by ERISA and the Pension Benefit Guaranty Corporation, within a two year time frame from the point of our withdrawal, we could have additional liability. We currently do not have plans to withdraw from any other multi-employer pension plan.

Withdrawal liabilities, requirements to pay increased contributions and/or excise taxes in connection with any of the multi-employer pension plans in which we participate could negatively impact our liquidity and results of operations. See Note 12 – Other Retirement Plans in the notes to consolidated financial statements for additional details.

Indemnities. We generally indemnify our customers for the services we provide under our contracts, as well as other specified liabilities, which may subject us to indemnity claims, liabilities and related litigation. As of December 31, 2011, we were not aware of any material asserted or unasserted claims in connection with these indemnity obligations.

Other Guarantees. In the ordinary course of business, from time to time, we guarantee the obligations of our subsidiaries, including obligations under certain contracts with customers, certain lease obligations and in some states, obligations in connection with obtaining contractors’ licenses. We also generally warrant the work we perform for a one to two year period following substantial completion of a project. We have not historically accrued any reserves for potential warranty claims as they have been immaterial.

Impact of Inflation

The primary inflationary factors affecting our operations are labor and fuel costs, and to a lesser extent, material costs. Although we did experience increases in these costs in 2011 as compared with 2010, the increases in labor and material costs were primarily due to revenue growth, changes in business mix, and for labor costs, productivity levels on certain project work. Fuel costs have increased versus 2010 from higher prices as well as to revenue growth and business mix. The price of fuel is subject to unexpected fluctuations due to events outside of our control, including geopolitical events and fluctuations in global supply and demand. Significant fuel price increases could adversely impact our operating results in the future. We closely monitor inflationary factors and any impact they may have on our operating results or financial condition.

 

53


Table of Contents

Recently Issued Accounting Pronouncements

See Note 1– Business, Basis of Presentation and Significant Accounting Policies in the notes to the consolidated financial statements.

 

ITEM 7A. QUANTITATIVE AND QUALITATIVE DISCLOSURES ABOUT MARKET RISK

Interest Rate Risk

Interest on outstanding revolving loans under our Credit Facility accrues at variable rates based, at our option, on a eurocurrency rate, as defined in the Credit Facility, plus a margin of 2.00%, or a base rate, as defined in the Credit Facility, plus a margin of 1.00%. As of December 31, 2011, interest on outstanding revolving loans accrued at a rate of 2.94% per annum. Interest on letters of credit issued under our Credit Facility currently accrues at either 1% or 2% per annum, based on the type of letter of credit issued, as defined in the Credit Facility. A 100 basis point increase in our interest rate on revolving loans under our Credit Facility would not have had a material impact on our 2011 results of operations.

Our fixed interest rate debt primarily includes $150 million in 7.625% senior notes, $115 million in 4.0% senior convertible notes, $100 million in 4.25% senior convertible notes and a $13.5 million 3.5267% equipment term loan, none of which debt subjects us to interest rate risk.

Foreign Currency Risk

In April 2011, we expanded our foreign operations through our acquisition of Fabcor, a Canadian natural gas and petroleum pipeline infrastructure construction company. As of December 31, 2011, we had operations in certain foreign countries, including Canada, Latin America and the Caribbean. For the year ended December 31, 2011, we had foreign currency translation losses of $1.6 million, relating primarily to our Canadian operations, which were recorded as a component of other comprehensive income. Due to the recent acquisition of Fabcor and/or if we otherwise expand our operations outside of the United States, our exposure to fluctuations in foreign currency exchange rates could increase in the future.

Auction Rate Securities

Our securities available for sale consist of auction rate securities. Our auction rate securities represent interests in pools of student loans guaranteed by the U.S. government under the Federal Family Education Loan Program and a structured finance security. The structured finance security has an attached credit default swap under which the principal value would be partially or fully forfeited at net default rates on the underlying corporate debt obligations ranging from 8% to 9% as of December 31, 2011. The actual net default rate as of December 31, 2011 was estimated to be 5.56%. Both the structured finance security and the credit default swap are collateralized by investment grade credit-linked notes made up of floating rate international bank notes. For the year ended December 31, 2011, $0.6 million of other-than-temporary impairment losses were recognized in earnings on our structured finance security, with a corresponding reduction in its cost basis. As of December 31, 2011, we hold $17.9 million in par value of auction rate securities, with an estimated fair value and carrying value of $13.6 million. Cumulative unrealized losses related to our student loan auction rate securities total $1.0 million as of December 31, 2011, which are recorded in other comprehensive income, net of applicable income taxes. During the second quarter of 2011, the issuer of one of our student loan auction rate securities redeemed its security at the security’s par value of $4.6 million. In connection with the redemption, $0.5 million of cumulative unrealized losses, along with the corresponding tax impact, were eliminated from other comprehensive income.

See Note 6 – Securities Available for Sale in the notes to consolidated financial statements.

 

54


Table of Contents
ITEM 8. FINANCIAL STATEMENTS AND SUPPLEMENTARY DATA

Index to Consolidated Financial Statements

 

     Page  

Report of Independent Registered Public Accounting Firm

     56   

Consolidated Statements of Operations for the Years Ended December 31, 2011, 2010 and 2009

     57   

Consolidated Balance Sheets as of December 31, 2011 and 2010

     58   

Consolidated Statements of Changes in Shareholders’ Equity for the Years Ended December  31, 2011, 2010 and 2009

     59   

Consolidated Statements of Cash Flows for the Years Ended December 31, 2011, 2010 and 2009

     60   

Notes to Consolidated Financial Statements

     61   

 

55


Table of Contents

REPORT OF INDEPENDENT REGISTERED PUBLIC ACCOUNTING FIRM

The Board of Directors and

Shareholders of MasTec, Inc.

We have audited the accompanying consolidated balance sheets of MasTec, Inc. and subsidiaries as of December 31, 2011 and 2010 and the related consolidated statements of operations, changes in shareholders’ equity, and cash flows for each of the three years in the period ended December 31, 2011. In connection with our audits of the consolidated financial statements, we have also audited the schedule listed in Item 15(a)2. These financial statements and the schedule are the responsibility of the Company’s management. Our responsibility is to express an opinion on these financial statements and schedule based on our audits.

We conducted our audits in accordance with the standards of the Public Company Accounting Oversight Board (United States). Those standards require that we plan and perform the audit to obtain reasonable assurance about whether the financial statements and schedule are free of material misstatement. An audit includes examining, on a test basis, evidence supporting the amounts and disclosures in the financial statements. An audit also includes assessing the accounting principles used and significant estimates made by management, as well as evaluating the overall presentation of the financial statements and schedule. We believe that our audits provide a reasonable basis for our opinion.

In our opinion, the financial statements referred to above present fairly, in all material respects, the consolidated financial position of MasTec, Inc. as of December 31, 2011 and 2010, and the consolidated results of their operations and their cash flows for each of the three years in the period ended December 31, 2011 in conformity with accounting principles generally accepted in the United States of America.

Also, in our opinion, the financial statements schedules, when considered in relation to the basic consolidated financial statements takes as a whole, presents fairly, in all material respects, the information set forth therein.

We also have audited, in accordance with the Standards of the Public Company Accounting Oversight Board (United States), the effectiveness of MasTec, Inc.’s internal control over financial reporting as of December 31, 2011, based on criteria established in Internal Control – Integrated Framework issued by the Committee of Sponsoring Organizations of the Treadway Commission (COSO) and our report dated February 29, 2012 expressed an unqualified opinion thereon.

 

/s/ BDO USA, LLP

Certified Public Accountants
Miami, Florida
February 29, 2012

 

56


Table of Contents

MASTEC, INC.

CONSOLIDATED STATEMENTS OF OPERATIONS

(in thousands, except per share amounts)

 

     2011     2010     2009  

Revenue

   $ 3,008,977      $ 2,308,031      $ 1,623,502   

Costs of revenue, excluding depreciation and amortization

     2,606,091        1,938,882        1,376,125   

Depreciation and amortization

     75,228        57,966        49,539   

General and administrative expenses

     148,432        126,658        96,932   

Interest expense, net

     34,423        29,105        24,690   

Gain on remeasurement of equity interest in acquiree

     (29,041     —          —     

Other (income) expense, net

     (183     1,420        (2,917
  

 

 

   

 

 

   

 

 

 

Income before provision for income taxes

   $ 174,027      $ 154,000      $ 79,133   

Provision for income taxes

     (68,055     (63,613     (8,385
  

 

 

   

 

 

   

 

 

 

Net income

   $ 105,972      $ 90,387      $ 70,748   

Net loss attributable to non-controlling interests

     (29     (141     —     
  

 

 

   

 

 

   

 

 

 

Net income attributable to MasTec

   $ 106,001      $ 90,528      $ 70,748   
  

 

 

   

 

 

   

 

 

 

Earnings per share – basic and diluted (See Note 2 - Earnings Per Share)

      

Basic net income per share attributable to MasTec

   $ 1.29      $ 1.19      $ 0.93   
  

 

 

   

 

 

   

 

 

 

Basic weighted average common shares outstanding

     82,182        76,132        75,701   
  

 

 

   

 

 

   

 

 

 

Diluted net income per share attributable to MasTec

   $ 1.23      $ 1.05      $ 0.90   
  

 

 

   

 

 

   

 

 

 

Diluted weighted average common shares outstanding

     86,718        90,913        81,763   
  

 

 

   

 

 

   

 

 

 

The accompanying notes are an integral part of these consolidated financial statements.

 

57


Table of Contents

MASTEC, INC.

CONSOLIDATED BALANCE SHEETS

(in thousands, except shares and per share amounts)

 

     December 31,
2011
    December 31,
2010
 

Assets

    

Current assets:

    

Cash and cash equivalents, including restricted cash of $18,000 as of December 31, 2010

   $ 20,280      $ 177,604   

Accounts receivable, net of allowance

     664,629        444,363   

Inventories

     88,992        57,483   

Deferred tax assets, net

     10,596        11,990   

Prepaid expenses and deposits

     22,078        17,176   

Other current assets

     15,935        13,058   
  

 

 

   

 

 

 

Total current assets

   $ 822,510      $ 721,674   

Property and equipment, net

     266,583        180,786   

Goodwill

     807,850        613,369   

Other intangible assets, net

     117,946        78,190   

Securities available for sale

     13,565        18,997   

Investments in unconsolidated entities

     1,408        11,972   

Other assets

     51,283        30,840   
  

 

 

   

 

 

 

Total assets

   $ 2,081,145      $ 1,655,828   
  

 

 

   

 

 

 

Liabilities and Shareholders’ Equity

    

Current liabilities:

    

Current maturities of long-term debt

   $ 34,191      $ 18,399   

Accounts payable

     306,996        196,363   

Accrued salaries and wages

     38,136        33,079   

Accrued taxes payable

     5,747        15,269   

Accrued insurance

     19,306        16,616   

Other accrued expenses

     11,934        13,329   

Acquisition-related contingent consideration, current

     21,833        35,639   

Billings in excess of costs and earnings

     109,723        136,070   

Other current liabilities

     32,381        21,780   
  

 

 

   

 

 

 

Total current liabilities

   $ 580,247      $ 486,544   

Acquisition-related contingent consideration

     74,563        34,695   

Other liabilities

     31,789        24,789   

Deferred tax liabilities, net

     122,614        62,487   

Long-term debt

     460,725        394,151   
  

 

 

   

 

 

 

Total liabilities

   $ 1,269,938      $ 1,002,666   
  

 

 

   

 

 

 

Commitments and contingencies (See Note 16)

    

Shareholders’ equity:

    

Preferred stock, $1.00 par value; authorized shares - 5,000,000; issued and outstanding shares - none

   $ —        $ —     

Common stock, $0.10 par value; authorized shares - 145,000,000; issued shares - 85,162,527 and 78,215,189 as of December 31, 2011 and 2010, respectively

     8,516        7,822   

Capital surplus

     792,096        663,927   

Accumulated surplus (deficit)

     93,489        (12,512

Accumulated other comprehensive loss

     (7,946     (6,156

Treasury stock, at cost; shares as of December 31, 2011 - 4,593,663; shares as of December 31, 2010 - none

     (75,000     —     
  

 

 

   

 

 

 

Total MasTec shareholders’ equity

     811,155        653,081   

Non-controlling interests

     52        81   
  

 

 

   

 

 

 

Total shareholders’ equity

   $ 811,207      $ 653,162   
  

 

 

   

 

 

 

Total liabilities and shareholders’ equity

   $ 2,081,145      $ 1,655,828   
  

 

 

   

 

 

 

The accompanying notes are an integral part of these consolidated financial statements.

 

58


Table of Contents

MASTEC, INC.

CONSOLIDATED STATEMENTS OF CHANGES IN SHAREHOLDERS’ EQUITY

(in thousands, except shares)

 

          Common Stock and Additional
Paid-In Capital
    Treasury Stock                          
    Comprehensive
Income
    Shares     Amount     Capital
Surplus
    Accumulated
(Deficit)
Surplus
    Shares     Amount     Accumulated
Other

Comprehensive
Loss
    Total
MasTec
Shareholders’

Equity
    Non-
Controlling
Interests
    Total
Shareholders’
Equity
 

Balance December 31, 2008

  $ 57,443        75,454,565      $ 7,545      $ 622,745      $ (173,788     —        $ —        $ (13,412   $ 443,090      $ —        $ 443,090   
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Net income

  $ 70,748            $ 70,748            $ 70,748        $ 70,748   

Foreign currency translation adjustment

    (134               $ (134     (134       (134

Unrealized gains, net of tax

    3,641                    3,641        3,641          3,641   

Reclassification adjustment for impairment loss included in earnings, net of tax

    3,781                    3,781        3,781          3,781   

Non cash stock compensation

        $ 3,065                3,065          3,065   

Stock options exercised

      381,814      $ 38        2,955          $            2,993          3,971   

Other stock issuances

      117,625        13        965                978       
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Balance December 31, 2009

  $ 78,036        75,954,004      $ 7,596      $ 629,730      $ (103,040     —        $ —        $ (6,124   $ 528,162      $ —        $ 528,162   
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Net income

  $ 90,528            $ 90,528            $ 90,528      $ (141   $ 90,387   

Foreign currency translation adjustment

    75                  $ 75        75          75   

Unrealized losses, net of tax

    (1,399                 (1,399     (1,399       (1,399

Reclassification adjustment for impairment loss included in earnings, net of tax

    714                    714        714          714   

Reclassification adjustment for unrealized loss on sale of securities, net of tax

    578                    578        578          578   

Acquisition of non-controlling interest

                      222        222   

Issuance of common stock in connection with acquisition related earn-out

      1,875,000      $ 188      $ 26,857                27,045          27,045   

Non cash stock compensation

          3,872                3,872          3,444   

Stock options exercised

      231,599        23        2,601                2,624          3,934   

Other stock issuances

      154,586        15        867                882       
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Balance December 31, 2010

  $ 90,496        78,215,189      $ 7,822      $ 663,927      $ (12,512     —        $ —        $ (6,156   $ 653,081      $ 81      $ 653,162   
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Net income

  $ 106,001            $ 106,001            $ 106,001      $ (29   $ 105,972   

Foreign currency translation adjustment

    (1,630                 (1,630     (1,630       (1,630

Unrealized losses, net of tax

    (445                 (445     (445       (445

Reclassification adjustment for unrealized loss on redemption of securities, net of tax

    285                    285        285          285   

Issuance of common stock in connection with acquisition

      5,129,642        513        93,700                94,213          94,213   

Fair value, senior convertible notes conversion feature, net of tax

          10,739                10,739          10,739   

Non cash stock compensation

          3,573                3,573          3,573   

Excess tax benefits from stock based compensation

          7,766                7,766          7,766   

Stock options exercised

      1,132,396        113        11,609                11,722          11,722   

Other stock issuances

      685,300        68        782                850          850   

Treasury stock acquired, at cost

              (4,593,663     (75,000       (75,000       (75,000
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Balance December 31, 2011

  $ 104,211        85,162,527      $ 8,516      $ 792,096      $ 93,489        (4,593,663   $ (75,000   $ (7,946   $ 811,155      $ 52      $ 811,207   
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

The accompanying notes are an integral part of these consolidated financial statements.

 

59


Table of Contents

MASTEC, INC.

CONSOLIDATED STATEMENTS OF CASH FLOWS

(in thousands)

 

     Year Ended December 31,  
     2011     2010     2009  

Cash flows from operating activities:

      

Net income

   $ 105,972      $ 90,387      $ 70,748   

Adjustments to reconcile net income to net cash provided by operating activities:

      

Depreciation and amortization

     75,228        57,966        49,539   

Stock-based compensation expense

     3,573        3,872        3,065   

Excess tax benefit from stock-based compensation

     (7,766     —          —     

Non-cash interest expense

     7,552        3,252        2,098   

Provision for doubtful accounts

     2,016        2,895        2,414   

Provision for losses on construction projects, net

     10,509        434        1,301   

Provision for inventory obsolescence

     1,709        300        302   

Impairment of securities available for sale

     574        1,164        6,119   

Gain on disposal of assets

     (76     (907     (1,334

(Earnings)/losses on equity method investments

     (27     321        —     

Gain on remeasurement of equity interest in acquiree

     (29,041     —          —     

Changes in assets and liabilities, net of assets acquired and liabilities assumed:

      

Accounts receivable

     (180,839     (127,724     85,044   

Inventories

     (29,151     (25,363     956   

Deferred tax assets and liabilities, net

     22,696        56,360        8,577   

Other assets, current and non-current portion

     (23,426     (5,614     12,878   

Accounts payable and accrued expenses

     73,099        67,137        (26,547

Billings in excess of costs and earnings

     (34,712     86,201        (7,851

Other liabilities, current and non-current portion

     7,936        7,348        (83,170
  

 

 

   

 

 

   

 

 

 

Net cash provided by operating activities

   $ 5,826      $ 218,029      $ 124,139   
  

 

 

   

 

 

   

 

 

 

Cash flows (used in) provided by investing activities:

      

Cash paid for acquisitions, net, including contingent consideration

     (85,395     (75,896     (157,619

Payments to acquire equity method investees

     —          (10,854     —     

Capital expenditures

     (71,710     (30,383     (21,859

Proceeds from sale of assets

     6,227        7,037        4,171   

Payments to acquire other investments

     —          (750     —     

Proceeds from sales or redemptions of investments

     4,600        7,044        —     

Investments in life insurance policies

     (284     (478     (717
  

 

 

   

 

 

   

 

 

 

Net cash used in investing activities

   $ (146,562   $ (104,280   $ (176,024
  

 

 

   

 

 

   

 

 

 

Cash flows (used in) provided by financing activities:

      

Proceeds from issuance of senior convertible notes

     —          —          215,000   

Proceeds from credit facility

     370,411        —          35,682   

Repayments of credit facility

     (310,411     —          (78,150

Proceeds from other borrowings and overdrafts incurred

     14,906        13,543        —     

Repayments of other borrowings

     (13,956     (27,170     (71,436

Payments of capital lease obligations

     (16,458     (14,460     (2,711

Proceeds from stock options exercises and other share-based awards

     12,542        3,515        3,971   

Excess tax benefit from stock-based compensation

     7,766        —          —     

Purchases of treasury stock

     (75,000     —          —     

Payments of financing costs

     (6,589     (169     (9,079
  

 

 

   

 

 

   

 

 

 

Net cash used in financing activities

   $ (16,789   $ (24,741   $ 93,277   
  

 

 

   

 

 

   

 

 

 

Net (decrease) increase in cash and cash equivalents

     (157,525     89,008        41,392   

Net effect of currency translation on cash

     201        75        (134

Cash and cash equivalents - beginning of period

     177,604        88,521        47,263   
  

 

 

   

 

 

   

 

 

 

Cash and cash equivalents - end of period

   $ 20,280      $ 177,604      $ 88,521   
  

 

 

   

 

 

   

 

 

 
Supplemental cash flow information:       

Interest paid

   $ 27,607      $ 27,385      $ 22,985   

Income taxes paid, net of refunds

   $ 27,803      $ 5,694      $ 2,147   
Supplemental disclosure of non-cash information:       

Equipment acquired under capital lease

   $ 7,412      $ 2,243      $ 1,901   

Equipment acquired under financing arrangement

   $ 25,788      $ —        $ —     

Conversion of leases from operating to capital

   $ 23,366      $ —        $ —     

Shares issued for business combinations

   $ 94,213      $ 27,045      $ —     

The accompanying notes are an integral part of these consolidated financial statements.

 

60


Table of Contents

MASTEC, INC.

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

Note 1 – Business, Basis of Presentation and Significant Accounting Policies

Nature of the Business

MasTec, Inc. (collectively with its subsidiaries, “MasTec” or the “Company”) is a leading infrastructure construction company operating mainly throughout North America across a range of industries. The Company’s activities include the engineering, building, installation, maintenance and upgrade of energy, utility and communications infrastructure, such as: electrical utility transmission and distribution; power generation; natural gas and petroleum pipeline infrastructure; wireless, wireline and satellite communications; wind farms, solar farms and other renewable energy; industrial infrastructure; and water and sewer systems. MasTec’s customers are primarily in the utility, communications and government industries.

Principles of Consolidation

The accompanying consolidated financial statements include MasTec, Inc. and its subsidiaries and include the accounts of all majority-owned subsidiaries over which the Company exercises control and, when applicable, entities in which the Company has a controlling financial interest. Other parties’ interests in companies for which MasTec exercises control and has a controlling financial interest are reported as non-controlling interests within shareholders’ equity. Net income or loss attributable to non-controlling interests is reported as a separate line item below net income. The Company’s investments in entities for which the Company does not have a controlling interest, but has the ability to exert significant influence, are accounted for using the equity method of accounting. Equity method investments are recorded as long-term assets in the consolidated balance sheets. Income or loss from these investments is recorded in other income or expense, net, in the consolidated statements of operations. The cost method is used for investments in entities for which the Company does not have the ability to exert significant influence. All significant intercompany balances and transactions have been eliminated in consolidation.

Management Estimates

The preparation of financial statements in conformity with accounting principles generally accepted in the United States (“U.S. GAAP”) requires management to make estimates and assumptions that affect the amounts reported in the financial statements and accompanying notes. Key estimates include: the recognition of revenue, in particular, on long-term construction contracts, including estimates to complete and provisions for contract losses; allowances for doubtful accounts; accrued self-insured claims; estimated fair values of goodwill and intangible assets, acquisition-related contingent consideration, investments in equity method investees, securities available for sale and certain convertible debt obligations; asset lives used in computing depreciation and amortization, including amortization of intangible assets; accounting for income taxes; and the estimated impact of contingencies and ongoing litigation. While management believes that such estimates are fair when considered in conjunction with the consolidated financial position and results of operations taken as a whole, actual results could differ from those estimates and such differences may be material to the financial statements.

Significant Accounting Policies

The following is a summary of significant accounting policies followed in the preparation of the accompanying consolidated financial statements.

Translation of Foreign Currencies

The assets and liabilities of foreign subsidiaries are translated into U.S. dollars at period-end exchange rates, with resulting translation gains or losses accumulated within other comprehensive income. Revenue and expenses are translated into U.S. dollars at average rates of exchange prevailing during the period. Translation gains or losses resulting from foreign currency transactions are included in other income or expense, net. The Company does not currently have any subsidiaries that operate in highly inflationary environments.

Reclassifications

Certain prior year amounts have been reclassified to conform to the current period presentation.

 

61


Table of Contents

Comprehensive Income

Comprehensive income is a measure of net income and all other changes in equity that result from transactions other than those with shareholders. Comprehensive income consists of net income, foreign currency translation adjustments, unrealized gains and losses from securities available for sale, and losses from non-controlling interests.

Accumulated other comprehensive losses of $7.9 million and $6.2 million as of December 31, 2011 and 2010, respectively, are primarily attributable to unrealized losses on securities available for sale, net of tax, and foreign currency translation losses and/or gains.

Revenue Recognition

Revenue and related costs for master and other service agreements billed on a time and materials basis are recognized as the services are rendered. Services are also performed under master and other service agreements billed on a fixed fee basis. Under fixed fee master service and similar type service agreements, MasTec furnishes various specified units of service for a separate fixed price per unit of service. For service agreements on a fixed fee basis, profitability will be reduced if the actual costs to complete each unit exceed original estimates.

Revenues from fixed price contracts are recognized using the percentage-of-completion method, measured by the percentage of costs incurred to date to total estimated costs for each contract. These contracts provide for a fixed amount of revenues for the entire project. Such contracts provide that the customer accept completion of progress to date and compensate the Company for services rendered, which may be measured in terms of units installed, hours expended or some other measure of progress. Contract costs include all direct materials, labor and subcontracted costs and those indirect costs related to contract performance, such as indirect labor, supplies, tools, repairs and the operational costs of capital equipment (excluding depreciation). Much of the materials associated with the Company’s work are customer-furnished and are therefore not included in contract revenues and costs. The cost estimation process is based on the professional knowledge and experience of the Company’s engineers, project managers and financial professionals. Changes in job performance, job conditions and final contract settlements are factors that influence management’s assessment of total contract value and the total estimated costs to complete those contracts and therefore, the Company’s profit recognition. Changes in these factors may result in revisions to costs and income, and their effects are recognized in the period in which the revisions are determined. Provisions for losses on uncompleted contracts are made in the period in which such losses are determined to be probable and the amount can be reasonably estimated.

The Company may incur costs subject to change orders, whether approved or unapproved by the customer, and/or claims related to certain contracts. Management determines the probability that such costs will be recovered based upon evidence such as engineering studies and legal opinions, past practices with the customer, specific discussions, correspondence or preliminary negotiations with the customer. The Company treats project costs as a cost of contract performance in the period incurred if it is not probable that the costs will be recovered, or defers costs and/or recognizes revenue up to the amount of the related cost if it is probable that the contract price will be adjusted and can be reliably estimated.

Billings in excess of costs and estimated earnings on uncompleted contracts are classified as current liabilities. Costs and estimated earnings in excess of billings, or work in process, is within classified as current assets for the majority of the Company’s projects. Work in process on contracts is based on work performed but not yet billed to customers as per individual contract terms.

Allowance for Doubtful Accounts

The Company maintains an allowance for doubtful accounts for estimated losses resulting from the inability of its customers to make required payments. Management analyzes the collectibility of accounts receivable and the adequacy of the allowance for doubtful accounts on a regular basis, based on the aging of account balances, historical bad debt experience, customer concentrations, customer credit-worthiness, customer financial condition and credit reports, availability of mechanics’ and other liens, existence of payment bonds and other sources of payment and current economic trends. For reporting units where losses have occurred historically and are considered to be ordinary course, reserves are established for anticipated losses based an analysis of the accounts receivable portfolio. For reporting units where historical losses have been immaterial, an increase in the allowance for doubtful accounts is recorded when it is probable a receivable is not collectible and the loss can be reasonably estimated. Amounts are written off against the allowance when deemed uncollectible.

Cash and Cash Equivalents

All short-term highly liquid investments with original maturities of three months or less are considered to be cash equivalents and are stated at cost, which approximates market value. Restricted cash as of December 31, 2010 included in cash and cash equivalents was invested in certificates of deposit with maturities equal to or less than 90 days, and represented cash deposited in support of letters of credit issued through the Company’s credit facility, which provided full availability for those funds, and no reduction in liquidity. There was no restricted cash as of December 31, 2011.

Cash Overdrafts. On a daily basis, available funds are swept from the Company’s depository accounts into a concentration account and are used to repay debt under the Company’s amended credit facility (the “Credit Facility”), which provides for a $600 million senior secured revolving credit facility maturing on August 22, 2016. Cash overdrafts principally represent the balance of outstanding checks that have not yet cleared through the banking system. Other cash balances maintained by certain operating subsidiaries, which are not swept into

 

62


Table of Contents

the concentration account, as well as deposits made subsequent to the daily cash sweep, are classified as cash. The Company generally does not fund its disbursement accounts for checks it has written until the checks are presented to the bank for payment. Cash overdrafts are classified within accounts payable. There are no compensating balance requirements associated with the Company’s depository accounts, and, with the exception of cash balances maintained by certain operating subsidiaries that are not available for sweep, there are no other restrictions on the transfer of cash associated with the Company’s depository accounts. As of December 31, 2011, cash overdrafts totaled $14.9 million.

Fair Value of Financial Instruments

The Company’s financial instruments include cash and cash equivalents, accounts and notes receivable, cash collateral deposited with insurance carriers, cash surrender value of life insurance policies, auction rate securities, cost and equity method investments, deferred compensation plan assets and liabilities, accounts payable and other current liabilities, acquisition-related contingent consideration and debt obligations.

Fair value is the price that would be received to sell an asset or paid to transfer a liability (an exit price) in the principal or most advantageous market for the asset or liability in an orderly transaction between market participants on the measurement date. The fair value guidance establishes a valuation hierarchy, which requires maximizing the use of observable inputs when measuring fair value. The three levels of inputs that may be used are:

 

  Level 1 -   Quoted market prices in active markets for identical assets or liabilities.
  Level 2 -   Observable market based inputs or other observable inputs.
  Level 3 -   Significant unobservable inputs that cannot be corroborated by observable market data. These values are generally determined using valuation models incorporating management’s estimates of market participant assumptions.

Fair values of financial instruments are estimated through the use of public market prices, quotes from financial institutions and other available information. Due to their short-term maturity, the carrying amounts of cash and cash equivalents, accounts and notes receivable and accounts payable and other current liabilities approximate their fair values. Management believes the carrying values of cash collateral deposited with insurance carriers, deferred compensation plan assets and liabilities and outstanding balances on the Company’s credit facility approximate their fair values. Cost and equity method investments are initially recorded at their cost basis. The fair value of the Company’s cost and equity method investments are not readily available, however, disclosure of their fair value is not required. Management is not aware of events or changes in circumstances that would have a material adverse effect on the carrying value of the Company’s cost or equity method investments.

See Note 5 – Fair Value of Financial Instruments for estimated fair values and carrying amounts of the Company’s other financial instruments.

Securities Available For Sale

The Company’s securities available for sale consist of auction-rate securities, which represent interests in pools of student loans guaranteed by the U.S. government under the Federal Family Education Loan Program and a structured finance security. The structured finance security has an attached credit default swap under which the principal value of the structured finance security would be partially or fully forfeited at net default rates on the underlying corporate debt obligations ranging from 8% to 9% as of December 31, 2011. The actual net default rate as of December 31, 2011 was estimated to be 5.56%. Both the structured finance security and the credit default swap are collateralized by investment grade credit-linked notes made up of floating rate international bank notes.

Liquidity for auction rate securities was originally intended to be provided by an auction process that would reset the applicable interest rate at pre-determined intervals, usually every 7, 28 or 35 days. Due to disruptions in the credit markets beginning in 2008, these auctions have not had sufficient bidders to allow investors to complete a sale, indicating that immediate liquidity at par is unavailable. As a result, there was insufficient observable market data to determine the fair value of the Company’s auction rate securities as of December 31, 2011 and 2010. Therefore, their respective fair values were estimated by an independent valuation firm, Houlihan Capital Advisors, LLC, using a probability-weighted discounted cash flow model. The model incorporates assumptions that market participants would use in their estimates of fair value, such as reset interest rates, final stated maturities, collateral values, credit quality and insurance, and applies the probabilities of either (a) a successful auction; (b) a failed auction; or (c) a default; at each auction. This valuation is sensitive to market conditions and management’s judgment and can change significantly based on the assumptions used. Factors that may impact the valuation include: changes to credit ratings of the securities and, for the structured finance securities, changes to the credit ratings of the underlying assets supporting the securities as well as rates of default of the underlying assets, underlying collateral values, discount rates, counterparty risk and ongoing strength and quality of market credit and liquidity.

Due to the liquidity issues associated with the Company’s auction-rate securities, they have been recorded in the Company’s financials at their estimated fair value as long-term assets. Temporary unrealized holding gains and losses are recorded as a separate component of accumulated other comprehensive income (loss), net of applicable income taxes. Unrealized losses are charged against earnings when a decline in fair value is determined to be other-than-temporary. An impairment is considered to be other-than-temporary if an entity intends to sell a security, more likely than not will be required to sell a security before recovering its cost, or does not expect to recover a security’s entire amortized cost basis, even if there is no intent to sell the security.

 

63


Table of Contents

The Company considers several factors in assessing whether a loss is other-than-temporary. These factors include, but are not limited to: intent to hold a security; that it is not more likely than not that the Company will be required to sell a security before recovery of its cost basis; the length of time a security is in an unrealized loss position; the extent to which fair value is less than cost; the financial condition and near term prospects of the issuer; changes to the credit ratings of securities, as well as their underlying assets; and, for the Company’s structured finance security, rates of default on the underlying portfolio of credit default swaps.

In assessing the expectation of recovering a security’s amortized cost basis, management performs an assessment of the present value of cash flows expected to be collected. If this assessment yields an amount less than the amortized cost basis of the security, even if the Company has the intent, and more likely than not, the ability to hold the securities, a credit loss is deemed to exist. The amount of an other-than-temporary impairment attributed to the credit losses is recognized in earnings, while the amount of an other-than-temporary impairment related to other factors is recognized in other comprehensive income, net of applicable deferred income taxes. The Company estimates credit losses associated with its auction rate securities using Level 3 inputs. Credit loss estimates are derived by comparing the estimated fair value of the securities, which are based on a number of factors, including estimated probabilities of default, with the value that would have been derived if the probability of default for the same securities were zero percent. The difference between the recorded fair value and the estimated fair value assuming a zero probability of default is considered the portion of total decline in fair value attributable to credit losses.

See Note 6 – Securities Available for Sale for further discussion.

Inventories

Inventories consist of materials and supplies for construction and install to the home projects. Inventories are valued at the lower of cost (using the specific identification method) or market. Construction projects are completed pursuant to customer specifications. For materials or supplies purchased on behalf of specific customers or projects, loss of the customer or cancellation of the project could result in an impairment of the value of materials purchased. Technological or market changes can also render certain materials obsolete. Allowances for inventory obsolescence are determined based upon the specific facts and circumstances and market conditions. As of December 31, 2011 and 2010, inventory obsolescence reserves were immaterial.

Deferred Costs

Deferred financing costs related to the Company’s credit facility, senior notes and senior convertible notes, whose short and long-term portions are included in other current and non-current assets in the consolidated balance sheets, are amortized over the related terms of the debt using the effective interest method. Net deferred financing costs were $8.2 million and $11.2 million at December 31, 2011 and 2010, respectively.

Software Capitalization

The Company capitalizes certain costs incurred in connection with developing or obtaining internal use software. These capitalized software costs are included in property and equipment, net, in the consolidated balance sheets and are amortized over a period not to exceed seven years.

Business Combinations – Valuation of Acquired Assets and Liabilities

Allocations of purchase price for business combinations are based on estimates of the fair value of consideration paid and the net assets acquired. Accounting for business combinations requires estimates and judgments as to expectations of future cash flows for acquired businesses and the allocation of those cash flows to identifiable tangible and intangible assets in determining the estimated fair values of assets acquired and liabilities assumed. The fair values assigned to tangible and intangible assets and liabilities, including contingent consideration, are based on management’s estimates and assumptions, utilizing customary valuation procedures and techniques. See Note 5 – Fair Value of Financial Instruments for the Company’s policy on fair value estimates. Contingent consideration is measured at its estimated fair value as of the date of acquisition, with subsequent changes in fair value recorded in earnings as a component of other income or expense. If actual results differ significantly from the estimates and judgments used in determining the estimated fair values of assets and liabilities recorded as of the date of acquisition, these differences could result in a possible impairment of recorded assets, including intangible assets and goodwill, or require acceleration of amortization expense of finite-lived intangible assets.

Long-Lived Assets

The Company’s long-lived assets consist primarily of property and equipment and finite-lived intangible assets. Property and equipment are recorded at cost, or if acquired in a business combination, at acquisition date fair value. Depreciation is computed using the straight-line method over the estimated useful lives of the respective assets. Leasehold improvements are depreciated over the shorter of the term of the lease or the estimated useful lives of the improvements. Property and equipment under capital leases are depreciated over their estimated useful lives. Expenditures for repairs and maintenance are charged to expense as incurred. Expenditures for betterments and major improvements are capitalized and depreciated over the remaining useful lives of the assets. The carrying amounts of assets sold or retired and

 

64


Table of Contents

related accumulated depreciation are eliminated in the year of disposal and the resulting gains and losses are included in other income or expense. Acquired intangible assets that have finite useful lives are recognized and amortized over their useful lives, which are generally based on contractual or legal rights.

Management reviews its long-lived assets for impairment whenever events or changes in circumstances indicate that their carrying amounts may not be realizable. If an evaluation is required, the estimated future undiscounted cash flows associated with the asset are compared to the asset’s carrying amount to determine if there has been an impairment. The amount of an impairment is calculated as the difference between the fair value of the asset and its carrying value. Estimates of future undiscounted cash flows are based on management’s view of growth rates for the related business, anticipated future economic conditions and estimates of residual values. Estimated fair values take into consideration appropriate discount rates relative to risk. Management believes that these estimates are consistent with assumptions that marketplace participants would use in their estimates of fair value. For the years ended December 31, 2011, 2010 and 2009, no material impairment charges were incurred relating to the Company’s long-lived assets.

Goodwill and Indefinite-Lived Intangible Assets

Goodwill and certain intangible assets acquired in a business combination and determined to have infinite useful lives are not amortized, but instead tested for impairment at least annually. Management conducts a review of the Company’s reporting units to determine if the carrying values of the reporting units exceed their estimated fair values During the year ended December 31, 2011, the Company adopted ASU 2011-08, which permits an entity to first assess qualitative factors to determine whether it is more likely than not that the fair value of a reporting unit is less than its carrying amount as a basis for determining whether it is necessary to perform the traditional two-step goodwill impairment test. During each of the two years in the period ended December 31, 2010, management estimated the fair value of the Company’s reporting units using a discounted cash flow methodology. This analysis requires several estimates, including future cash flows and growth rates for the reporting units, as well as the selection of a discount rate. Goodwill impairment may exist if the net book value of the reporting unit exceeds its estimated fair value. Should this be the case, the value of goodwill may be impaired and a write down may be required. See Note 4 – Goodwill and Other Intangible Assets.

Self-Insurance

MasTec maintains insurance policies subject to per claim deductibles of $1 million for its workers’ compensation policy, $2 million for its general liability policy and $2 million for its automobile liability policy. The Company has excess umbrella coverage up to $100 million per claim and in the aggregate. Liabilities under these insurance programs are accrued based upon management’s estimates of the ultimate liability for claims reported and an estimate of claims incurred but not reported with assistance from third-party actuaries. The present value of the Company’s self-insurance liabilities are reflected in the consolidated balance sheets as current and other non-current liabilities. These insurance liabilities are difficult to assess and estimate due to unknown factors, including the severity of an injury, the determination of the Company’s liability in proportion to other parties and the number of incidents not reported. Accruals are based upon known facts and historical trends and management believes such accruals to be adequate. However, a change in experience or actuarial assumptions could materially affect results of operations in a particular period. MasTec also maintains an insurance policy with respect to employee group health claims, which is subject to annual per employee maximum losses of $0.4 million. MasTec’s liability for employee group claims is based on statistical analysis of historical claims experience and specific knowledge of actual losses that have occurred.

The Company is required to post letters of credit and provide cash collateral to certain of its insurance carriers and to obtain surety bonds in certain states in which the Company is self-insured. A portion of these letters of credit was collateralized by $18.0 million of restricted cash as of December 31, 2010. In addition, the Company has certain cash collateral deposited with insurance carriers, which is included in other long-term assets in the consolidated balance sheets.

Income Taxes

The Company records income taxes using the asset and liability method of accounting for deferred income taxes. Under this method, deferred tax assets and liabilities are recognized for the expected future tax consequence of temporary differences between the financial statement and income tax basis of the Company’s assets and liabilities. Income taxes are estimated in each of the jurisdictions in which the Company operates. This process involves estimating the tax exposure together with assessing temporary differences resulting from differing treatment of items, such as deferred revenue, for tax and accounting purposes. These differences result in deferred tax assets and liabilities, which are included within the consolidated balance sheets. The recording of a net deferred tax asset assumes the realization of such asset in the future. Otherwise, a valuation allowance must be recorded to reduce this asset to its net realizable value. Management considers future pretax income and ongoing prudent and feasible tax planning strategies in assessing the net realizable value of tax assets and the need for such a valuation allowance. In the event that management determines that the Company may not be able to realize all or part of a net deferred tax asset in the future, a valuation allowance for the deferred tax asset is charged against income in the period such determination is made.

In determining the provision for income taxes, management uses an effective tax rate based on annual pre-tax income, permanent tax differences, statutory tax rates and tax planning opportunities in the various jurisdictions in which the Company operates. Significant factors that impact the annual effective tax rate include management’s assessment of certain tax matters, the location and amount of taxable earnings, changes in certain non-deductible expenses and expected credits.

 

65


Table of Contents

The Company’s subsidiaries file income tax returns in numerous tax jurisdictions, including U.S. federal, most U.S. states and certain foreign jurisdictions. The statute of limitations varies by the various jurisdictions in which the Company operates. The Company’s U.S. federal income tax returns for years ending on or after December 31, 2008 remain open for examination. Although management believes its calculations for tax returns are correct and the positions taken thereon are reasonable, the final outcome of tax audits could be materially different from the resolution management currently anticipates, and those differences could result in significant costs or benefits to the Company. If applicable, any interest or penalties pertaining to the Company’s income tax returns, if assessed, would be recorded within interest expense or general and administrative expense, respectively, in the Company’s consolidated statements of operations.

Stock-Based Compensation

The Company has granted to employees and others restricted stock and options to purchase common stock. Non-cash stock compensation expense for administrative employees is included in general and administrative expense, and for operational employees, is included within cost of sales in the consolidated statements of operations. Share-based payments, to the extent they are compensatory, are recognized based on their grant date fair values and the estimated number of shares ultimately expected to vest. The Company records a deferred tax asset, or future tax benefit, based on the amount of share-based compensation recognized in the financial statements over the vesting period of share-based awards. If the exercise date fair value of a stock option, or the vesting date fair value of a restricted share award exceeds its grant date fair value, the tax effect of this difference (“excess tax benefit”) is recorded as an increase to additional paid-in capital (“APIC”), creating an “APIC Pool.” If the exercise date fair value of a stock option, or the vesting date fair value of a restricted share award is less than its grant date fair value, the tax effect of this difference would reduce the APIC Pool. If the APIC Pool is reduced to zero, subsequent shortfalls would increase tax expense.

Grants of restricted stock are valued based on the market price of MasTec’s common stock on the date of grant. Compensation expense arising from restricted stock grants with graded vesting is recognized using the ratable method (an accelerated method of expense recognition) over the vesting period. Those shares issued with cliff vesting are amortized on a straight line basis over the vesting period. Vesting periods for grants of restricted stock range from day of issuance to five years. For certain restricted share awards, the number of shares issued on the vesting date is net of the number of shares having the value required to satisfy the recipient’s minimum statutory tax withholding requirements. The Company then pays the corresponding withholding taxes to the appropriate taxing authorities in cash on behalf of the recipient. Although the withheld shares are not issued, they are treated as common stock repurchases in the consolidated financial statements, as they reduce the number of shares that would have been issued upon vesting.

Stock option grants vest between one to five years after grant, have a term not to exceed ten years, and are generally forfeited in the holder terminates his or her employment or relationship with the Company or one of its affiliates. All option plans contain anti-dilutive provisions that require adjustment of the number of shares of common stock represented by each option for any stock splits or dividends. No stock options have been granted since 2006. For stock options granted in prior periods, the Black-Scholes valuation model was used to estimate the fair value of options to purchase MasTec’s common stock, which is no less than the fair market value of the underlying stock on the date of grant. The Company uses the ratable method to amortize compensation expense over the vesting period of the option grant. All outstanding grants were fully vested as of December 31, 2010.

See Note 11 – Stock-Based Compensation Plans for further discussion.

Multi-Employer Pensions Plans

The Company makes contributions to certain union-administered multi-employer pension plans, which are recorded as a component of employee wages and salaries within costs of revenue. Contributions are generally based on fixed amounts per hour per employee for employees covered under these plans. To the extent that those plans are underfunded, the Employee Retirement Income Security Act of 1974, as amended by the Multi-Employer Pension Plan Amendments Act of 1980, may subject the Company to substantial liabilities if the Company withdraws from such multi-employer plans or if they are terminated. In November 2011, the Company voluntarily withdrew from one of the multi-employer pension plans in which it participates and recorded a charge of $6.4 million within costs of revenue. Withdrawal liabilities under multi-employer pension plans are based on estimates of the Company’s proportionate share of the plan’s unfunded vested liability, as calculated by the plan’s actuaries, and represent the Company’s best estimate of such liabilities as of the time such withdrawal liabilities are recorded.

See Note 12 – Other Retirement Plans and Note 16 – Commitments and Contingencies for additional details.

Treasury Stock

The Company records treasury shares at cost. See Note 13 – Common Stock Activity.

New accounting pronouncements

Recently Adopted Accounting Pronouncements

In April 2010, the FASB issued ASU 2010-17, Milestone Method of Revenue Recognition, a consensus of the FASB Emerging Issues Task Force (“ASU 2010-17”). This update provides guidance on defining a milestone under Topic 605, Revenue Recognition –

 

66


Table of Contents

Milestone Method, and determining when it may be appropriate to apply the milestone method of revenue recognition for research or development transactions. Consideration that is contingent on achievement of a milestone in its entirety may be recognized as revenue in the period in which the milestone is achieved only if the milestone is judged to meet certain criteria to be considered substantive. Milestones should be considered substantive in their entirety and may not be bifurcated. An arrangement may contain both substantive and nonsubstantive milestones that should be evaluated individually. ASU 2010-17 is effective on a prospective basis for milestones achieved in fiscal years, and interim periods within those years, beginning on or after June 15, 2010 with early adoption permitted. The adoption of ASU 2010-17 as of January 1, 2011 did not have a material impact on the Company’s financial statements.

In December 2010, the FASB issued ASU 2010-28, Intangibles–Goodwill and Other (Topic 350): When to Perform Step 2 of the Goodwill Impairment Test for Reporting Units with Zero or Negative Carrying Amounts (“ASU 2010-28”). ASU 2010-28 modifies Step 1 of the goodwill impairment test for reporting units with zero or negative carrying amounts. For those reporting units, an entity is required to perform Step 2 of the goodwill impairment test if it is more likely than not that a goodwill impairment exists. In determining whether it is more likely than not that a goodwill impairment exists, an entity should consider whether there are any adverse qualitative factors indicating that an impairment may exist. ASU 2010-28 is effective for fiscal years, and interim periods within those years, beginning after December 15, 2010. The adoption of ASU 2010-28 effective January 1, 2011 did not have a material impact on the Company’s consolidated financial statements.

In December 2010, the FASB issued ASU 2010-29, Business Combinations (Topic 805): Disclosure of Supplementary Pro Forma Information for Business Combinations, a consensus of the FASB Emerging Issues Task Force (“ASU 2010-29”). The objective of ASU 2010-29 is to address diversity in practice relating to the interpretation of pro forma revenue and earnings disclosure requirements for business combinations. Under ASU 2010-29, comparative financial statements should disclose revenue and earnings of the combined entity as if the business combinations that have occurred during the current year had been in effect as of the beginning of the comparable prior annual reporting period only. Additionally, ASU 2010-29 expands the supplemental pro forma disclosures under Topic 805 to include a description of the nature and amount of material, nonrecurring pro forma adjustments directly attributable to the business combinations included in reported pro forma revenue and earnings. ASU 2010-29 is effective prospectively for business combinations acquired on or after the beginning of the first annual reporting period beginning on or after December 15, 2010. See related disclosures in Note 3 – Goodwill and Other Intangible Assets.

In September 2011, the FASB issued ASU 2011-09, CompensationRetirement BenefitsMultiemployer Plans (Subtopic 715-80): Disclosures about an Employer’s Participation in a Multiemployer Plan (“ASU 2011-09”). ASU 2011-09 requires additional disclosures about an employer’s participation in a multiemployer pension plan (“MEPP”). Incremental disclosures include the significant MEPPs in which the Company participates, level of participation, financial health of significant MEPPs and the nature of commitments to MEPPs. ASU 2011-09 is effective for annual periods for fiscal years ending after December 15, 2011, with retrospective application for all prior periods presented. See related disclosures in Note 12 – Other Retirement Plans.

In September 2011, the FASB issued ASU 2011-08, IntangiblesGoodwill and Other (Topic 350): Testing Goodwill for Impairment (“ASU 2011-08”). ASU 2011-08 permits an entity to first assess qualitative factors to determine whether it is more likely than not that the fair value of a reporting unit is less than its carrying amount as a basis for determining whether it is necessary to perform the two-step goodwill impairment test described in Topic 350, Intangibles-Goodwill and Other. The more-likely-than-not threshold is defined as having a likelihood of greater than 50%. ASU 2011-08 is effective for fiscal years beginning after December 15, 2011, with early adoption permitted. The Company adopted ASU 2011-08 in connection with its 2011 annual goodwill impairment assessment. See Note 4 – Goodwill and Other Intangible Assets.

Recently Issued Accounting Standards, Not Adopted as of December 31, 2011

In May 2011, the FASB issued ASU 2011-04, Fair Value Measurement (Topic 820): Amendments to Achieve Common Fair Value Measurement and Disclosure Requirements in U.S. GAAP and International Financial Reporting Standards (“ASU 2011-04”). The objective of ASU 2011-04 is to converge guidance of the FASB and the International Accounting Standards Board on fair value measurement and disclosure. This update changes the wording used to describe many of the requirements in U.S. GAAP for measuring fair value and disclosing information about fair value measurements; clarifies the FASB’s intent about the application of existing fair value measurement requirements; and changes particular principles or requirements for measuring fair value or for disclosing information about fair value measurements. ASU 2011-04 is effective prospectively for interim and annual periods beginning after December 15, 2011. The Company is currently evaluating the potential impact of this standard on the Company’s consolidated financial statements.

In June 2011, the FASB issued ASU 2011-05, Comprehensive Income (Topic 220): Presentation of Comprehensive Income (“ASU 2011-05”). The objective of ASU 2011-05 is to improve the comparability, consistency and transparency of financial reporting and to increase the prominence of items reported in other comprehensive income. ASU 2011-05 provides the option to present the total of comprehensive income, the components of net income and the components of other comprehensive income either in a single continuous statement of comprehensive income or in two separate but consecutive statements. ASU 2011-05 eliminates the option to present the components of other comprehensive income as part of the statement of changes in shareholders’ equity. In December 2011, the FASB issued ASU 2011-12, Deferral of the Effective Date for Amendments to the Presentation of Reclassifications of Items Out of Accumulated Other Comprehensive Income in ASU 2011-05 (“ASU 2011-12”), which defers those provisions in ASU 2011-05 relating to the presentation of reclassification adjustments. ASU 2011-12 reinstates the requirements for the presentation of reclassifications out of accumulated other

 

67


Table of Contents

comprehensive income that were in place before ASU 2011-05. The remaining provisions of ASU 2011-05 are effective retrospectively for annual periods, and interim periods within those years, beginning after December 15, 2011. ASU 2011-12 is effective for reporting periods beginning after December 15, 2011. The Company is currently evaluating the potential impact of this standard on its consolidated financial statements.

In December 2011, the FASB issued ASU 2011-11, Disclosures about Offsetting Assets and Liabilities (“ASU 2011-11”). ASU 2011-11 requires disclosure of gross and net information about instruments and transactions that are eligible for offset in the statement of financial position or that are subject to an enforceable master netting arrangement or similar agreement, such as derivatives, sale and repurchase agreements and securities borrowing and lending arrangements. ASU-2011-11 is effective for annual reporting periods and interim periods within those years, beginning on or after January 1, 2013, with retrospective application for all comparative periods presented. The Company does not anticipate that this pronouncement will have a material impact on its consolidated financial statements.

Note 2 – Earnings Per Share

Basic earnings per share is computed by dividing earnings available to MasTec’s common shareholders by the weighted average number of common shares outstanding for the period. Diluted earnings per share is computed on the basis of fully diluted shares and earnings, which includes the effect of potentially dilutive common shares. Potentially dilutive common shares include outstanding stock options and unvested restricted share awards, as calculated under the treasury stock method, as well as shares associated with the Company’s outstanding convertible securities.

As described in Note 9 – Debt, the Company had convertible notes outstanding during each of the three years in the period ended December 31, 2011. During the first quarter of 2011, the Company exchanged $105.3 million of its original 4.0% senior convertible notes (the “Original 4.0% Notes”) and $97.0 million of its original 4.25% senior convertible notes (the “Original 4.25% Notes” and, together with the Original 4.0% Notes, the “Original Notes”) for identical principal amounts of new 4.0% and 4.25% senior convertible notes (the “New 4.0% Notes” and the “New 4.25% Notes,” respectively and, collectively, the “New Notes”). The terms of the New Notes are substantially identical to the Original Notes, except that the New Notes have an optional physical (share), cash or combination settlement feature and contain certain conditional conversion features. Due to the optional cash settlement feature and management’s intent to settle the principal amount thereof in cash, the conversion shares underlying the outstanding principal amount of the New Notes, totaling approximately 13.0 million shares, are not required to be included in the Company’s diluted share count. If, however, the Company’s average stock price per share for the corresponding period exceeds the $15.76 conversion price for the New 4.0% Notes or the $15.48 conversion price for the New 4.25% Notes, the resulting amount, in shares, of the premium over the principal amount is included in the Company’s diluted share count (“premium shares”).

The number of common shares issuable upon conversion of the Company’s Original Notes is reflected in the calculation of diluted earnings per share for the corresponding periods by application of the “if-converted” method to the extent their effect is dilutive. Under the “if-converted” method, net income is adjusted to add back the after-tax amount of interest recognized in the period associated with the convertible notes, and correspondingly, the convertible notes are assumed to have been converted with the resulting common shares added to weighted average shares outstanding. Premium shares associated with the New Notes are reflected in the calculation of diluted earnings per share to the extent that the Company’s average stock price for the corresponding periods exceeds the respective conversion prices of the New Notes, beginning with the date of issuance, or the beginning of the period, as applicable.

The following table summarizes the principal amounts of the Company’s outstanding convertible notes for the periods indicated, including their respective classification within the computation of earnings per share for each period (in millions):

 

     Year Ended December 31,  
     2011      2010      2009  

Dilutive:

        

New 4.0% Notes (1)

   $ 105.3         N/A         N/A   

New 4.25% Notes (1)

     97.0         N/A         N/A   

Original 4.0% Notes (2)

     9.7       $ 115.0       $ 115.0   

Original 4.25% Notes (2)

     3.0         100.0         100.0   
  

 

 

    

 

 

    

 

 

 

Total principal amount, dilutive outstanding convertible notes

   $ 215.0       $ 215.0       $ 215.0   
  

 

 

    

 

 

    

 

 

 

Anti-dilutive:

        

8.0% convertible notes

     N/A         N/A       $ 55.0   
  

 

 

    

 

 

    

 

 

 

 

(1) Diluted shares associated with the New Notes are attributable to the premium over the respective conversion prices.
(2) Diluted shares associated with the Original Notes are attributable to the underlying principal amounts.

 

68


Table of Contents

The Company’s average stock price for the year ended December 31, 2011 exceeded the conversion prices of the New Notes. The number of premium shares included in the Company’s diluted share count varies with fluctuations in the Company’s actual share price for the related periods. Higher actual share prices result in a greater number of equivalent premium shares. Details of the calculation underlying the number of premium shares included in the Company’s diluted share count for the period indicated are as follows (in thousands, except per share amounts):

 

     Year Ended December 31, 2011  
     New 4.0%  Senior
Convertible Notes
     New 4.25% Senior
Convertible Notes
 

Principal amount

   $ 105,322       $ 97,000   

Conversion price per share

   $ 15.76       $ 15.48   
  

 

 

    

 

 

 

Number of conversion shares, principal amount

     6,683         6,268   
  

 

 

    

 

 

 

Weighted average actual per share price

   $ 18.90       $ 18.88   
  

 

 

    

 

 

 

Excess over principal amount

   $ 20,968       $ 21,319   
  

 

 

    

 

 

 

Weighted average equivalent premium shares

     1,067         1,095   
  

 

 

    

 

 

 

The following table provides details of the Company’s earnings per share calculations for the periods indicated (in thousands, except per share amounts):

 

     Year Ended December 31,  
     2011      2010      2009  

Basic

        

Net income attributable to MasTec

   $ 106,001       $ 90,528       $ 70,748   

Weighted average shares outstanding

     82,182         76,132         75,701   
  

 

 

    

 

 

    

 

 

 

Basic earnings per share attributable to MasTec

   $ 1.29       $ 1.19       $ 0.93   
  

 

 

    

 

 

    

 

 

 

Diluted

        

Net income:

        

Basic net income attributable to MasTec

   $ 106,001       $ 90,528       $ 70,748   

Interest expense on Original 4.0% Notes, net of tax

     331         2,700         2,260   

Interest expense on Original 4.25% Notes, net of tax

     154         2,494         419   
  

 

 

    

 

 

    

 

 

 

Diluted net income attributable to MasTec

   $ 106,486       $ 95,722       $ 73,427   
  

 

 

    

 

 

    

 

 

 

Shares:

        

Basic weighted average shares outstanding

     82,182         76,132         75,701   

Dilutive common stock equivalents

     1,129         1,022         1,025   

Dilutive premium shares, New 4.0% Notes

     1,067         —           —     

Dilutive premium shares, New 4.25% Notes

     1,095         —           —     

Dilutive shares, Original 4.0% Notes

     862         7,297         4,134   

Dilutive shares, Original 4.25% Notes

     383         6,462         903   
  

 

 

    

 

 

    

 

 

 

Diluted weighted average shares outstanding

     86,718         90,913         81,763   
  

 

 

    

 

 

    

 

 

 

Diluted earnings per share attributable to MasTec

   $ 1.23       $ 1.05       $ 0.90   
  

 

 

    

 

 

    

 

 

 

For the year ended December 31, 2011, the weighted average number of anti-dilutive common stock equivalents that were not included in the Company’s diluted earn